Line 3 (Mumbai Metro)
|Locale||Mumbai, Maharashtra, India|
|Daily ridership||1.39 million (2021 estimate)|
|Owner||Mumbai Metro Rail Corporation Ltd (MMRC)|
|Character||Underground and at grade|
|Depot(s)||Aarey Milk Colony|
|Line length||33.05 km (20.54 mi)|
|Number of tracks||2|
|Track gauge||1,435 mm (4 ft 8 1⁄2 in) standard gauge|
|Electrification||Overhead 25kV AC|
|Mumbai Metro (Line 3)|
Metro 3 of the Mumbai Metro, also referred to as the Colaba–Bandra-SEEPZ line, is a part of the metro system for the city of Mumbai, India of which construction has been initiated. When completed, the 33.5-km long line will be the first underground metro line in Mumbai. The metro line will connect Cuffe Parade business district in the extreme south of the city to SEEPZ in the north-central with 26 underground and one at-grade station. The track width is standard gauge. The cost of this corridor is estimated at ₹23,136 crore (US$3.2 billion). Line 3 is expected to reduce road congestion, besides reducing the load on the Western Line between Bandra and Churchgate.
The project is being implemented by the Mumbai Metro Rail Corporation Limited (MMRCL). The line starts at Cuffe Parade, will run through Nariman Point, Churchgate, CST, Girgam, Worli, Dadar, Mahim, Kalina University, Bandra, Bandra-Kurla Complex, Santacruz East and past the domestic and international terminals of Mumbai Airport, through Andheri MIDC and terminates at SEEPZ.
A 1.2 km section of the line between Bandra Kurla Complex and Dharavi stations will pass under the Mithi river. This will be the second underwater metro rail tunnel in India after the tunnel below the Hooghly river on Kolkata Metro Line 2.
The 33.5 km, Rs. 23,136 crore project involves five major entities - MMRCL (Mumbai Metro Rail Corporation Limited), Padeco, MMRDA, CREC (China), . Major (65%) funding for the project was received through a soft loan of Rs. 13,235 crore from JICA (Japan International Cooperation Agency) with the rest provided by the exchequer through the Government of India and Government of Maharashtra.
A 20 km metro line from Colaba to Bandra was announced in January 2014, as part of a master plan unveiled by the Mumbai Metropolitan Region Development Authority (MMRDA). The plan encompassed a total of 146 kilometres (91 mi) of track, of which 32 kilometres (20 mi) was proposed to be underground. The MMRDA unveiled plans for an extended Colaba-Bandra-SEEPZ metro line in 2011. According to its earlier plans, a 20-km metro line from Colaba to Bandra was to be constructed, running underground for 10 kilometres (6.2 mi) from Colaba to Mahalaxmi, and then on an elevated track from Mahalaxmi to Bandra. The MMRDA decided to extend the line to the Chatrapati Shivaji International Airport to increase ridership. The 33.5-kilometre (20.8 mi) Colaba-Bandra-SEEPZ line was estimated to cost ₹21,000 crore (US$2.9 billion), have 27 stations, and would be the city's first fully underground metro line. at Nariman Point, BKC, MIDC, SEEPZ, and elsewhere. According to the MMRDA, an underground metro will minimise land acquisition and disturbance to traffic during construction compared to an elevated metro.
The Mumbai Metro Rail Corporation Ltd (MMRC), registered under provisions of Company Act, 1956, was constituted as a fully owned company of the MMRDA on 30 April 2008, as per state government directives. On 27 February 2012, the Central Government gave in-principle approval to the plan for Line 3. In April 2012, the MMRDA announced plans to grant the MMRC increased management autonomy, in an effort to enhance the project's operational efficiency.
In early 2012, the MMRDA conducted talks with officials at Chhatrapati Shivaji International Airport (CSIA) to finance or construct the line's three stations at the airport and GVK SkyCity, a proposed nearby commercial development. Mumbai International Airport Limited (MIAL) agreed to bear the cost of constructing the three stations, which is expected to total ₹777 crore. According to MIAL's CEO, R.K. Jain, MIAL is willing to contribute to the metro's construction because of the potential increase in passenger convenience. MIAL estimated the cost of developing the metro lines in the airport as ₹518 crore.
|Source||Amount (₹crores)||Share (%)|
|Equity by Centre||2,403||10.4|
|Equity by MMRC and State||2,403||10.4|
|Sub debt by Centre||1,025||4.4|
|Sub debt by State||1,615||7|
|Property development and impact fee||1,000||4.3|
|Stakeholder contribution (MIAL)||777||3.4|
|ASIDE funding / MMRDA grant||679||2.9|
In August 2012, the Urban Development Ministry rejected the Planning Commission's proposal to implement Line 3 in a public-private partnership (PPP) mode, having found the mode unsatisfactory for the Delhi Airport Metro Express. The ministry instead proposed a funding pattern with a ratio of 20:80 between the Centre and the State. Of the State equity, 45% was proposed to be through a loan from the Japan International Cooperation Agency (JICA).
In 2016, JICA commenced providing financial assistance for the project in the form of a soft loan through the MOUD (Ministry of urban development) as a "pass through assistance" at an annual rate of interest of 1.4% (interest free for monies given to consultants). This amounts to ₹13,235 crore (US$1.8 billion) for the ₹23,136 crore (US$3.2 billion) project. JICA will fund 57.2% of the equity. The soft loan has an interest rate of 1.44%. The other finance will come from the central and state equity of 10.4% each, sub-debt by the central government (4.4%), sub-debt by the state (7%), property development and impact fee (4.3%), stakeholder contribution from the Mumbai International Airport Ltd. (3.4%) and MMRDA grant/aside funding (2.9%).
The Union Cabinet granted clearance to Line 3 on 27 June 2013. The Cabinet also decide to convert Mumbai Metro Rail Corporation (MMRC), the existing state-level special purpose vehicle formed to implement metro projects, into a joint venture company of the state and central governments with equity participation. The MMRC's board consists of five members each from state and central governments. The MMRDA presented their metro line plan to the Brihanmumbai Municipal Corporation on 13 February 2014.
Line 3 was approved by the state cabinet on 26 February 2014. Line 3 is being implemented through the engineering, procurement and construction (EPC) model. The foundation stone for the project was laid by Chief Minister Prithviraj Chavan in a bhoomi pujan ceremony at Andheri on 26 August 2014, in the presence of Union Urban Development minister Venkaiah Naidu. The move was described by the media as a cosmetic gesture, as the developers of the project had not yet been decided and actual construction was expected to begin only by December 2014. The date of the ceremony was a few days before the code of conduct for the 2014 State Assembly elections would come into force, which would prohibit the ruling Congress-NCP government from politicising the ceremony. Some citizens protested against the State government at the ground breaking site. They protested the slow implementation and cost escalation of the Mumbai Metro project. Tendering for the project was delayed by the re-organization of the MMRC from a wholly owned entity of the State Government, to a joint venture between the Union and State Governments. Although the State Government received the file for reconstituting the company in October 2013, it gave approval only in July 2014.
In December 2014, the MMRC appointed a consortium led by Hong Kong-based AECOM Asia, in a joint venture with Padeco, Japan, LBG Inc. USA and Egis Rail, France as the general consultants for the implementation of the Line 3 project. The agreement between the two parties was signed on 26 May 2015. On 6 July 2015, the MMRC unveiled a new logo, designed by Design Orb, for Line 3. UPS Madan, Director, MMRC and Metropolitan Commissioner, MMRDA, explained, "The earlier logo was designed with an elevated Metro-3 corridor in mind as was planned originally. The new logo presents the organisation more appropriately as its more relevant, fresh and robust". He also noted that the earlier logo had been designed while the MMRC was owned by the State Government, while it was now a joint venture between the State and the Centre.
The MMRC will have to rehabilitate 2,807 families for the project. Most of the families were relocated to Kurla and Chakala. The MMRC also provided free hotel accommodation to people residing in old, dilapidated buildings along the metro corridor that were in danger of collapsing during tunneling work. The majority of such buildings were located in the Girgaum-Kalbadevi belt in South Mumbai.
The MMRC called for pre-qualification bids in September 2013. Bidders for the work on tunnels and stations were to submit their bids by 30 October 2013. On 31 January 2014, the bid document was modified and the annual turnover requirement was reduced to "average annual construction turnover of not less than USD 175 million defined as billing for civil infrastructure work completed or in progress over the last five years ending on March 2013". Sanjay Sethi, managing director of MMRC, stated, "The annual turnover requirement must have been set with the idea of attracting specific companies to the project. However, the Japan International Cooperation Agency (JICA) felt that consortia or joint ventures are a combination of management contractors and construction contractors. In all Metro projects, the annual turnover is the starting point for bidding based on which we should not restrict applications. The issue was also raised by several potential bidders." The last date for the submission of pre-qualification bids was extended to 10 March 2014. Fourteen pre-qualification bids were received for the design and construction of underground stations and tunnels for Line 3. The 14 bidders were: Afcon-KMB, CEC-ITD Cementation India-TPL, CTCEC-Pan India Infrastructures Pvt Ltd, Dogus-Soma Constructions, IL&FS-CR256 (China Railway), JKumar-CRTG, Larsen & Toubro-STEC, Mosmetrostory-Hindustan Construction Company, OHL-SK Engineering & Construction, Pratibha-GDYT Consortium, Sacyr-CMC-Essar, Salin Impreglio-Gammon, Strabag-AG-Patel Engineering and Unity Infrastructure-IVRCL-CTG. Tenders to construct the car depot at Aarey colony were floated by the MMRC in July 2014.
Of the 14 consortia that submitted pre-qualification bids, 9 were shortlisted in September 2014. According to Sanjay Sethi, managing director of MMRC, "We have finalised the list of companies eligible for bidding after getting an approval from the Japan International Cooperation Agency (JICA), which is providing more than 50 per cent of funds for the project. The companies that were declared ineligible mostly fell short in technical experience. The tender for construction of Line 3 received was split into seven packages, each consisting of a 4–5 km long twin tunnel. The tender floated by the MMRC received 31 bids from 9 consortiums. The first four packages received 4 bids each, while the next three packages received 5, 7 and 3 bids respectively. The 9 consortia were AFCONS Infrastructure Ltd. - Kyivmetrobud, Continental Engineering Corporation - ITD Cementation India Ltd - Tata Projects Ltd, DOGUS - SOMA, IL&FS Engineering and Construction Company Ltd - China Railway 25th Bureau Group Co.Ltd, J.Kumar Infraprojects Ltd - China Railway No.3 Engineering Group Co. Ltd, Larsen & Toubro Ltd/Shanghai Tunnel Engineering Co. Ltd, OSJC Moscow Metrostroy - Hindustan Construction Co.Ltd, Pratibha Industries Ltd - Guandong Yuantian Engineering Co., and Unity Infraprojects Ltd - IVRCL Ltd - China Railway Tunnel Group Co. Ltd.
In January 2017, the MMRC floated tenders worth ₹328 crore for the construction of the depot, a metro station, work workshop buildings at Aarey Colony and a vehicular underpass along the Marol Maroshi Road, with other allied works. The contract was awarded to New Delhi-based Sam (India) Builtwell Pvt. Ltd. in June 2017. The contract also includes the construction of about 2.5 km of storm water drains, a rain water harvesting system and the diversion of a 1,200 mm diameter MCGM water pipeline. Construction is expected to be completed by mid-2020.
|1 (Cuffe Parade–Hutatma Chowk)||Cuffe Parade, Vidhan Bhavan, Churchgate||Cut-and-cover||₹29.9 billion (US$420 million)||Larsen & Toubro and Shanghai Tunnel Engineering Co.|
|2 (CST Metro–Grant Road)||CST Metro||Cut-and-cover||₹25.2 billion (US$350 million)||Hindustan Construction Co and Moscow Metrostroy|
|Grant Road, Kalabadevi, Girgaon||NATM|
|3 (Mumbai Central–Worli)||Central Metro, Mahalaxmi, Science Museum,
Worli, Acharya Atre Chowk
|C&C||₹25.6 billion (US$360 million)||Doğuş and Soma|
|4 (Siddhivinayak–Sitaladevi)||Siddhivinayak, Dadar||C&C||₹28.3 billion (US$390 million)||Continental Engineering Corp, ITD Cementation and Tata Projects|
|5 (Dharavi–Santacruz)||Dharavi, BKC, Vidyanagari||C&C||₹28.2 billion (US$390 million)||J Kumar Infraprojects and China Railway Tunnel Group|
|6 (CSIA–CSA International)||Domestic Airport, Sahar Airport, International Airport||C&C||₹21.2 billion (US$300 million)|
|7 (Marol Naka–SEEPZ)||Marol Naka||NATM||₹22.8 billion (US$320 million)||Larsen & Toubro and Shanghai Tunnel Engineering Co.|
|Aarey Colony||Aarey Depot||At grade||₹328 crore (US$46 million)||Sam (India) Builtwell Pvt. Ltd.|
The project will affect 5,012 trees, of which 1,331 will be cut and the remaining 3,681 will re-planted in other parts of the city. Per the terms of the contracts awarded to various consortia, they are in-charge of transplanting affected trees and planting new trees to make up for those cut down. The contract requires consortia to plant three times the number of trees cut down for the project, and maintain them for a period of at least 3 years. The consortium of Tata Projects, ITD Cementation and CEC Taiwan, which won the contract to construct the package 4, pledged to construct 4 times more trees than it was required to plant under the contract. The work on package 4, the section between Siddhivinayak Temple and Mahim, required the felling of 150 trees. The consortium pledged that it would plant 2,000 trees instead of the required 450.
On 28 February 2017, the MMRC announced that it would donate 25,000 saplings to housing societies, hospitals, and schools located along the metro line. The MMRC stated that the donation was in addition to compulsory tree plantation required by MCGM regulations. In January 2017, the MMRC hired arborist Simon Leong from Singapore to serve as a tree consultant on the project. Leong will provide his services for a six-month period at a rate of $33,000 per month. The MMRC donated 16,000 saplings at 25 different locations under its Project Neighbourhood initiative on 11 April 2017.
MMRC Director Ashwini Bhide criticized the controversy over the tree felling required for the project saying that infrastructure could not be built without cutting down trees. Bhide stated that the metro had been designed to minimize the loss of trees, and that 3 times more trees would be planted to make up for the loss. Bhide further explained that the 5,000 trees proposed to be cut for Metro 3 would reduce carbon dioxide by 6,100 kg, while reduction in vehicle usage as a result of Metro 3 would reduce carbon emissions by an estimated 9.9 million kg. Bhide also stated that the MMRC had considered considered building the depot at Kalina and Kanjurmarg but decided against it due to lack of availability of land and potential legal disputes involving land in the area.
Bombay High Court case
On 9 February 2017, the Bombay High Court issued an interim order prohibiting the MMRDA from cutting trees for the project. The Court was hearing two PILs filed by Mina Verma and Pravin Jehangir. Verma's PIL concerned tree felling in Churchgate, Colaba and Cuffe Parade, and Jehangir challenged the use of public lands for construction of the line. On 10 March 2017, the Court ordered the MMRC to furnish documents proving that it had received necessary clearance from the MoEF to construct the proposed stations of Hutatma Chowk, Churchgate and Cuffe Parade, or documents to prove that no clearances were required. The order was in response to the petitioner's claim that the MoEF had rejected the MMRC's request to construct the 3 stations. The MMRC responded that no clearance was required to construct the stations. On 16 March, the Court issued a notice to the MoEF asking it to clarify whether it had granted clearance to the MMRC to construct nine stations. The petitioner had pointed out that all nine stations fell under the Coastal Regulatory Zones II and III. On 12 April, the MMRDA filed its reply to petition declaring that the State Environment Impact Assessment Authority (SIEAA) had granted it permission to construct stations in Coastal Regulation Zone (CRZ) areas. The court directed the MMRDA and MMRC to submit all relevant supporting documents by 24 April. On 3 May, the Bombay High Court declared that the metro was crucial to ease traffic congestion in Mumbai. However, the court reserved its stay on tree felling stating that it would consider "what is more important - life of a human being or the life of tree". On 5 May, the High Court vacated its stay on tree felling for Metro 3. The Court declared that Metro 3 would help improve the environment and the socio-economic conditions of the city. It also observed that a balance had to be found between environmental protection and development, and that taking a "harsh stand, which the petitioners want" would make it "impossible to conduct development work".
On 8 May, the petitioners filed a special leave petition (SLP) in the Supreme Court challenging the High Court ruling. On 15 May 2017, the Supreme Court issued a stay on tree felling for the project until 18 May.
Aarey land issue
In 2015, the state government announced plans to construct the metro depot, where metro coaches will be parked, on an 81-acre plot of land in Aarey Colony. Authorities also intended to construct a labour camp for construction workers and a centralised operation control centre for the entire Mumbai Metro network at Aarey Colony. The construction would require the felling of more than 2,000 trees in the area. Environmental groups Vanashakti and Aarey Conservation Group (ACG) filed a petition with the National Green Tribunal (NGT) in January 2015 requesting that the Aarey Colony be protected as a no-development zone. On 5 December 2016, the Union Environment Ministry issued a notification declaring the area up to 4 km from the boundary of the Sanjay Gandhi National Park to be an eco-sensitive zone. The notification excluded 165 hectares of land in Aarey, in order to permit the construction of Line 3. However, the notification declared that the exclusion was sub-ordinate to any orders from the judiciary or the NGT.
The NGT's Pune bench passed an order temporarily staying all construction activities in Aarey on 19 December 2016. On 5 January 2017, the NGT granted an exemption permitting the MMRC to construct a casting yard on a 3-hectare plot of land owned by the State Government in Aarey. A tribunal bench ordered the forest department to provide a detailed map of Aarey Colony, and to declare whether any portion of the region had been identified as forests. In 1997, as part of a Supreme Court directive, State Governments had prepared a detailed map of urban forest cover. The forest department failed to provide the details at the next hearing, and on 17 February 2017, the NGT extended its stay on all construction activities up to 17 March 2017. On 29 March, the state forest department informed the NGT that 1,279.74 ha of land at Aarey had been used for non-forest activities since 1949, and therefore "cannot be declared a forest land because it is not a forest". The department clarified that although 1,114.74 ha of land had been declared as an eco-sensitive zone (ESZ) by the Union environment ministry on 5 December 2016, the notification excluded the land given to the MMRC and certain other areas. The department also stated that it would submit a list of survey numbers identifying Aarey as a non-forest area at the NGT's next hearing on 10 April. At the hearing on 10 April, the forest department stated that it was unable to locate its report on Aarey that would help prove that it was not "forest land", and requested an extension. The request was denied by the NGT. On 24 April, the Tribunal ordered the additional solicitor general to appear before it on 3 May and clarify the MoEF's position on approval for Metro 3.
Due to the issues surrounding the land at Aarey, Larsen & Toubro and Shanghai Tunnel Engineering Co., the consortium that was awarded the seventh package to carry out construction on the MIDC-Aarey Depot section of the line, exited the contract. The MMRC stated that the appointment of a new contractor would escalate the project cost by an addition ₹10 crore (US$1.4 million). The Court stated that it would determine if the cutting of nearly 5,000 trees for the project was necessary.
On 18 February 2017, Fadnavis directed the MMRDA to consider constructing the depot at Kanjurmarg or Kalina. A few weeks later, MMRC officials stated that the proposed depot could not be built at Mumbai University land in Kalina because the available area was too small. The MMRC insisted that the depot should be built at Aarey, but proposed a new design which would allow the depot to be construct on 25 hectares of land as compared to the 33 hectares required by the old design. The new design will reduce the number of trees to be cut by 1,000.
In March 2017, E. Sreedharan wrote to Chief Minister Fadnavis requesting him to ensure clearance for proposed metro depot at Aarey. Sreedharan wrote, "Metro projects are environmentally most friendly and setting up a carshed in Aarey is not going to be a threat either to the government or to the eco system. The main objection would be against cutting of trees, for which compensatory afforestation on a liberal scale can be insisted upon."
According reports in the media, the MMRC brought machinery to conduct soil testing work for constructing ramps in Aarey on 23 March. However, local business owners protested the work, alleging that the NGT had stayed all construction activities in Aarey. The MMRC stated that the stay only applied to construction of the car depot, and not the ramps. Due to the protests, contractors removed all machinery from the site on 25 March 2017. MMRC began soil testing at Aarey on 30 March 2017, under police protection. The work area was cordoned off and surrounded by 50 Mumbai Police personnel.
Construction of the Colaba-Bandra-Seepz metro involves a number of large national and supra national entities and sub contractors.. These sub contractors, mostly involved in the tunneling works and mostly joint ventures include L&T-STEC (A joint venture between Larsen & Toubra India and STEC a large Chinese infrastructure company based in Shanghai), CEC-ITD CEM-TPL, Dogus-Soma, HCC-MMS and J.Kumar-CRTG.. More than 100 Sub contractors and third parties have been used for various construction and relocation works including tunneling, boring, diversion of pipelines, realty consultancy and land acquisition including 
Two 5.2 metre diameter twin tunnels of 33.5 km each will be dug at a depth of 20–25 metres. Seventeen tunnel boring machines (TBMs), each weighing around 1400 tonnes and costing ₹120 crore (US$17 million), will be used to dig the tunnels. The TBMs will be lowered through shafts or pits using a specialized crane. Pre-cast segments will be put on the tunnels' diameter to prevent cave ins, after the TBMs bore 1.2 metres. Tunnels will have to be dug through a mix of soil and basalt rock, and is expected to be difficult. TBMs can dig at an average rate of 8 metres per day through rock, and at a rate of 14 metres per day through soil. After TBMs bore through section, the metro tunnel will be lined with pre-cast concrete rings to strengthen the tunnels. Boring and placing rings occurs sequentially. For the entire Metro 3 corridor, around 40,000 concrete rings were cast in 65 moulds. Casting of the rings took place at six casting yards - four in Wadala, one each at Darga, and on the Jogeshwari-Vikhroli Link Road (JVLR). The first concrete ring was fabricated at a Wadala casting yard on 7 March 2017.
Underground construction will be carried out at an average depth of 15 to 25 meters. The Hutatma Chowk, Kalbadevi, Girgaum, Grant Road, Shitladevi, Santacruz and Marol Naka stations will be constructed by the New Austrian Tunnelling method, while the other 20 stations will be constructed by the cut-and-cover method. In the latter method, the ground is dug, the entire station constructed, and finally the top is covered. Underground utilities will have to be shifted to construct the line, as it is completely underground.
A 1.2 km section of the line between Bandra Kurla Complex and Dharavi stations will pass under the Mithi river. The underwater tunnel will pass beneath the river bed. Authorities will also construct a stabling line at a depth of 12–13 meters below the river bed. The stabling line will extend up to BKC station, and will be used for stabling and reversing of trains.
The original deadline for the project was 2016, but it is currently expected to be completed in 2021. Construction work on the project began on 21 October 2016. The work has faced delays due to several legal disputes. In March 2017, MMRC officials stated that they were unable to proceed with full scale construction activities due to legal issues, and that contractors were currently carrying out other activities such as shifting utilities, geo-technical surveys, and fabricating pre-cast segments. Officials further added that if construction did not begin within one month, the project cost would escalate at the rate ₹4 crore (US$560,000) per day and would result in higher passenger fares. Authorities began full scale construction activities on 18 May 2017.
The alignment of Metro 3 at Chira Bazar in Marine Lines runs parallel to a Parsi fire temple. The trust that manages the temple forbids the entry of non-Parsis into the temple. As a result, contractors were unable to the enter the temple premises to map the location and conduct a building condition survey before beginning construction of the line. The trust instead requested the MMRC to hire a Parsi engineer to carry out the necessary work in the temple premises. The MMRC officials accepted the request and stated that it would work with temple authorities to avoid offending any religious beliefs and sentiments. However, with only about 57,000 Parsis residing in Mumbai, the agency faced difficulty completing the task.
Tunneling work on the corridor is expected to begin by October 2017. An estimated 6 million cubic metres of rubble will be excavated during tunneling, which will be sent to quarries on the outskirts of Mumbai. The rubble includes basalt rock of good quality that can be re-used in construction. Initial plans called for the rubble to be used for the foundation of the Shiv Smarak monument, and the proposed Mumbai coastal road project, but delays associated with the monument have made this unlikely.
On 10 July 2018, the MMRDA announced that it had completed 5,100 meters of tunneling for the corridor within the first year since the project was initiated. Around 10 km of tunneling was completed by September 2018.
The first phase of the line between Colaba and BKC is expected to open in 2020, and the remaining section will open in 2021.
Passenger interchange facilities will be provided at Chhatrapati Shivaji Terminus (Central Line); Churchgate, Mumbai Central and Mahalaxmi (Western Line), Marol Naka (Metro Line 1), Bandra-Kurla Complex (Metro Line 2) and Mahalaxmi (Mumbai Monorail).
Under the original plan, there was to be no direct connectivity between the airport and the metro. Commuters would have been required to exit the underground stations, return to ground level and cross a road to reach the airport. Upon reviewing the plan, Chief Minister Fadnavis directed the MMRC to redesign the stations to provide direct access between the underground and the airport as well as the Mumbai Central railway station.
|5||CST Metro||Central Line|
|8||Grant Road||Western Line|
|9||Mumbai Central Metro||Western Line|
|12||Acharya Atrey Chowk||None|
|18||BKC||Line 2 (Under Construction)|
|21||Domestic Airport||Line 7 (Under Construction)|
|22||Sahar Road||Line 7 (Under Construction)|
|23||International Airport||Line 7 (Under Construction)|
|24||Marol Naka||Line 1 (Operational)|
The car yard, where metro coaches will be parked, will be built opposite SEEPZ on an 81-acre plot in Aarey Colony.
In March 2017, the MMRC floated tenders for multiple works on Metro 3 including the traction system, power supply, tunnel ventilation, signalling, train control, platform screen doors and telecommunication system. The contracts include the manufacturing, supply and installation of these systems.
Tenders for design, supply, installation, testing and commissioning of ballastless tracks for the underground section were floated by the MMRC in May 2017.
The MMRC invited bids to supply rolling stock for Metro 3 in December 2015. The process of procuring rolling stock was delayed due to a disagreement between the Central Government and JICA. The Centre wanted 75% of the total rolling stock procured for the line to be manufactured in India, as part of its Make in India program, even if the contract was awarded to a foreign company. However, JICA wanted the bid for rolling stock to have no restrictions. The MMRC argued that manufacturing rolling stock in India would reduce the cost of maintenance. The agency stated that although bids without restrictions would result in cheaper procurement cost for the rolling stock, the subsequent cost of importing spare parts would be expensive. Under pressure from the NITI Aayog, the Department of Economic Affairs, and the Ministry of Urban Development, JICA agreed to accept the Union Government's domestic manufacturing requirement for rolling stock for all JICA-funded metro systems in India. As a result, the winning bidder may only manufacture a maximum 75% metro cars required for Metro 3 outside India. The MMRC rejected criticism that the restrictions would favour BEML, Bombardier and Alstom, the only companies that manufacture rolling stock in India, by stating that a foreign company that won the bid could sub-contract to an India-based manufacturer.
The MMRC restarted the bidding process, under the new conditions, in May 2017. The agency sought to procure 31 eight-car train sets. Each coach is 22.6 metres long and 3.2 metres wide. The MMRC received pre-qualification bids from seven firms - Alstom Transport India Ltd India & Alstom Transport S.A France (Consortium), CAF S.A, Spain, CRRC Nanjing, CRRC Changchun & CRRC International Corporation Ltd China (Consortium), Hitachi Ltd (Japan), Kawasaki Heavy Industries Japan & BHEL (Consortium) India, and Mitsubishi Corporation, Japan.
In September 2018, the MMRC awarded a EUR 315 million contract to French transportation major Alstom Transport and its Indian subsidiary to supply 248 coaches for Metro 3. The contractor will be responsible for the design, manufacture, supply, installation, testing and commissioning of 31 train sets of eight cars each. The trains will have a carrying capacity of 2,350 passengers and a seating capacity of around 300 passengers in each coach in longitudinal seating arrangements. All coaches will be designed and developed at Alstom's engineering centre in Bangalore, and manufactured by the company's plant in Sri City, Andhra Pradesh.
Metro 3 will be driverless. The line has an automation level of grade 4. However, the line will employ drivers during its first year in operation. Trains on the line will also utilize a time-interval system which allows them to maintain the minimum possible distance required for safety between each other. As all trains are connected with the operation control centre, every train is aware of the speed and distance of all other trains.
Metro 3 will utilise a communications-based train control (CBTC) signalling system. There are no signals on the line, and speed and distance between the trains is monitored by onboard computers that are connected with a central computer in the operations control centre.
MMRDA joint project director Dilip Kawathkar stated that AC power was chosen for Line 3 "after a proper study by a team of experts" which found that the AC model was "a better option". Experts believe that the decision to use AC escalated the project cost by 15%, since more digging is required for the rail to work on AC.
Despite providing connectivity to Mumbai's airport, passengers on Metro 3 will not be permitted to carry their check-in luggage onboard trains. Only hand/cabin baggage will be allowed. MMRC officials stated that Metro 3 was not an "Airport Express line", but a regular city metro corridor. Officials explained that providing luggage check-in would require additional dwell time at the Airport metro station, which would increase the overall headway of the line, and disrupt services for other passengers.
Metro 3 will utilize an open loop automated fare collection system. Passengers will be able to pay for travel using contactless pre-paid and post-paid smart cards issued by partnering banks. Only RuPay debit and credit cards will be accepted on Metro 3.
In March 2017, the MMRC held a pre-bid meeting with all pre-qualified bidders for the "Design, Manufacture, Supply, Installation, Testing and Commissioning of Tunnel Ventilation & Environmental Control System." In the same month, the agency received 12 bids from consortia to set up an automatic fare collection system.
- Detailed project report - Mumbai metro line 3 - Colaba-Bandra-Seepz (533 pages) (PDF). Mumbai: Mumbai metro raiul corporation limited / RITES (GOI). 1 November 2011. Retrieved 27 August 2018.
- "Mumbai: Underground Metro work to start in January 2015". NDTV.com. 2014-03-21. Retrieved 2014-03-27.
- "Official photo gallery - Mumbai metro". https://www.mmrcl.com. MMCL Official website. Retrieved 27 August 2018. External link in
- "Cabinet clears Mumbai Metro's third line". Times of India. 29 June 2013. Retrieved 7 July 2013.
- "Further delay in Colaba-Seepz metro as govt tweaks bid norms". Business Standard. 2014-02-04. Retrieved 2014-03-27.
- Manthan K Mehta (2014-03-25). "Metro phase III tenders to be issued by July 2013". The Times of India. TNN. Retrieved 2014-03-27.
- "Mumbai Metro Line 3 plan kicks off". Mumbai Mirror. 29 June 2013. Retrieved 7 July 2013.
- "Cabinet approves Mumbai Metro Line 3: FM". Zee News. 28 June 2013. Retrieved 7 July 2013.
- "Metro company to be revamped for Colaba-SEEPZ route - Times Of India". timesofindia.indiatimes.com. Retrieved 2014-01-25.
- "Complete list of official reports and documents". https://www.mmrcl.com. MMRCL - official website. Retrieved 27 August 2018. External link in
- "Metro-III gets Rs 4,553cr Japanese loan - Mumbai - DNA". Dnaindia.com. Retrieved 2013-09-28.
- "After Kolkata, Mumbai to be the second Indian city with underwater Metro tunnel". The Indian Express. 20 March 2017. Retrieved 20 March 2017.
- "Quick facts - MMRCL". https://www.mmrcl.com. MMRCL Official website. Retrieved 27 August 2018. External link in
- "Project documents". https://www.mmrcl.com. MMRC official website. Retrieved 27 August 2018. External link in
- Independent auditors report 2016-17 (PDF). New Delhi: RSVA & Co. 24 July 2017. Retrieved 27 August 2018.
- "Development body in talks with CSIA". The Indian Express. 14 January 2012. Retrieved 16 January 2012.
- "Views on Colaba-Seepz underground metro sought". DNA India. 14 December 2017. Retrieved 30 December 2011.
- "Public hearing to be held for Colaba-SEEPZ Metro line". Hindustan Times. 8 December 2011. Archived from the original on 21 January 2012. Retrieved 9 December 2011.
- "Underground Metro technically feasible: Study". The Indian Express. 2014-03-06. Retrieved 2014-03-27.
- "Mumbai Metro Rail Corporation". MMRDA. MMRDA. Archived from the original on 2 November 2013. Retrieved 4 March 2014.
Establishment of MMRC: As per State Govt. directives Mumbai Metro Rail Corporation (MMRC) has been constituted as fully owned company of MMRDA (registered under provisions of Company Act, 1956) as of 30th April, 2008. MMRC (at present) is responsible for the implementation of all the Metro Rail Corridors under Mumbai Metro Rail Project.
- "Centre paves way for 3rd Metro line". Times of India. 28 February 2012. Retrieved 28 March 2012.
- "Mumbai Metro likely to get autonomy status: MMRDA". DNA India. 27 April 2012. Retrieved 3 May 2012.
- "Mumbai airport plans Rs 1,600-crore upgrade". Business Standard. 2014-03-10. Retrieved 2014-03-27.
- "MIAL to build three stations near airport". The Indian Express. 5 March 2012. Retrieved 28 March 2012.
- "Ministry rejects Plan for Mumbai Metro-3". Daily Pioneer. 17 August 2012. Retrieved 21 August 2012.
- Independent auditors report 2016-17 (PDF). New Delhi. 1 July 2017. p. 37. Retrieved 27 August 2018.
- "Mumbai Metro 3 plan gets boost after Japan signs Rs 4,553 cr loan". Hindustan Times. 2013-09-18. Archived from the original on 21 September 2013. Retrieved 2013-09-28.
- "Japan's Rs 4K crore push for Mumbai Metro". Times of India. 30 May 2013. Retrieved 7 July 2013.
- "Japan sanctions $ 700 million loan for Mumbai Metro". IBN Live. 29 May 2013. Retrieved 7 July 2013.
- "Japan extends Rs 4553 crore loan for Mumbai Metro-3". Ibnlive.in.com. 2013-09-17. Retrieved 2013-09-28.
- "Colaba-Bandra Seepz Metro gets Cabinet nod". The Indian Express. 28 June 2013. Retrieved 7 July 2013.
- "If Metro-III meets its deadline, Mumbai will save Rs 1.60cr fuel daily by 2021". Times of India. 29 June 2013. Retrieved 7 July 2013.
- "Business Line: Cabinet approves Mumbai Metro Line-3 project". The Hindu. 28 June 2013. Retrieved 7 July 2013.
- Ateeq Shaikh (2014-02-23). "1.74L sq mts of land to be used for Colaba-Bandra-SEEPZ metro". Daily News & Analysis (DNA). Retrieved 2014-03-27.
- "Cabinet nod to Rs 23k cr Metro-III project". The Times of India. 2014-02-27. Retrieved 2014-03-27.
- "14 consortia show interest in Mumbai Metro's underground line". Business Standard. 2014-03-10. Retrieved 2014-03-27.
- "Archived copy". Archived from the original on 7 December 2014. Retrieved 2014-08-26.
- "Mumbai Metro III: MMRC to relocate 2,807 families". Free Press Journal. Retrieved 9 March 2017.
- "Mumbai Metro 3 work: Residents of old SoBo buildings to shift to hotels". Hindustan Times. 13 March 2017. Retrieved 14 March 2017.
- "SoBo residents may get free stay at hotels courtesy MMRC". Asian Age. 14 March 2017. Retrieved 14 March 2017.
- "Ball set rolling for underground Metro III; contract by March 2014 - Times Of India". Articles.timesofindia.indiatimes.com. 2013-09-18. Retrieved 2013-09-28.
- "Bids invited for 32.5 km Mumbai Metro III project design and construction". Business Standard. 2013-09-17. Retrieved 2013-09-28.
- "Eligibility norms eased to attract more bidders". The Indian Express. 2014-02-06. Retrieved 2014-03-27.
- "Metro-III project ready to chug along". The Indian Express. 2014-02-27. Retrieved 2014-03-27.
- "14 firms bid for city's 1st underground Metro line from Colaba to Seepz". The Indian Express. 2014-03-11. Retrieved 2014-03-27.
- "14 firms in race for underground work on Metro-3". The Times of India. 2014-03-11. Retrieved 2014-03-27.
- "14 companies in fray for Colaba-SEEPZ Metro Line-3 underground stations & tunnels". Mid-day.com. 2014-03-10. Retrieved 2014-03-27.
- UK, DVV Media. "Mumbai metro Line 3 work to begin in October". Railway Gazette. Retrieved 10 February 2017.
- "Contracts awarded for Mumbai Metro Line 3 construction works". The Global Rail Alliance. Retrieved 10 February 2017.
- "What is loss to environment? Metro will stop 10,000 metric tonnes of emissions, says Mumbai Metro Rail Director". The Indian Express. 8 May 2017. Retrieved 8 May 2017.
- "MMRC floats bids for Aarey Metro car depot". dna. 24 January 2017. Retrieved 10 February 2017.
- "MMRC awards contract for Metro carshed at Aarey". The Indian Express. 30 June 2017. Retrieved 5 July 2017.
- "Contractor appointed for Metro III car depot ignores protests by environmentalists - Times of India". The Times of India. Retrieved 5 July 2017.
- "5,012 trees will make way for Metro-3 project in Mumbai". Hindustan Times. 13 January 2017. Retrieved 10 February 2017.
- "Mumbai: Metro III to affect over 5,012 trees". Free Press Journal. Retrieved 10 February 2017.
- "Tata JV commits to plant 2,000 trees in Metro 3 notified area". The Hindu. Retrieved 3 March 2017.
- "Metro to gift 25,000 saplings to hospitals, schools - Times of India". The Times of India. Retrieved 28 February 2017.
- "At Rs 22 lakh a month, Metro gets specialist to transplant trees - Times of India". The Times of India. Retrieved 12 March 2017.
- "MMRC distributes 16K saplings across 25 location". India Today. Retrieved 13 April 2017.
- "Metro body distributes 16,000 saplings in Mumbai - Times of India". The Times of India. Retrieved 13 April 2017.
- "Metro 3 set to have driverless trains". Mumbai Mirror. Retrieved 3 March 2017.
- "Loss of 2800 trees looks horrifying, but the net environmental impact of the project will be positive - Mumbai Mirror -". Mumbai Mirror. Retrieved 7 March 2017.
- "'Metro will reduce 6.5 lakh vehicle trips per day' - Mumbai Mirror -". Mumbai Mirror. Retrieved 7 March 2017.
- "HC refuses to vacate stay on tree cutting for Metro-3". hindustantimes.com. 25 February 2017. Retrieved 25 February 2017.
- Correspondent, Special. "Metro 3: HC further stays cutting of trees". The Hindu. Retrieved 25 February 2017.
- "HC stay on plan to axe trees in south Bombay for Metro III to continue - Times of India". The Times of India. Retrieved 25 February 2017.
- "Produce green clearance documents for building three metro stations: Bombay HC". The Indian Express. 10 March 2017. Retrieved 11 March 2017.
- "Bombay high court asks if green nod was taken for Metro 3 stations in south Mumbai". Hindustan Times. 11 March 2017. Retrieved 11 March 2017.
- "Bombay HC seeks MoEF response over clearance to Metro 3 stations". The Indian Express. 17 March 2017. Retrieved 16 March 2017.
- "Mumbai: Loopholes in permission for Metro stations revealed". mid-day. Retrieved 17 March 2017.
- "Took permission for metro work in CRZ areas, says MMRC". http://www.asianage.com/. 13 April 2017. Retrieved 13 April 2017. External link in
- "Environment can't be massacred for development: HC to Mumbai Metro Rail Corporation". mid-day. Retrieved 13 April 2017.
- "Metro needed in Mumbai to ease traffic woes: HC". India Today. Retrieved 4 May 2017.
- "Need to decide if trees are more important than human lives: HC - Mumbai Mirror -". Mumbai Mirror. Retrieved 4 May 2017.
- Correspondent,, Special. "HC vacates stay on felling trees for Metro III project". The Hindu. Retrieved 8 May 2017.
- "Mumbai Metro: HC vacates stay on cutting of trees for Metro III project | Latest News & Updates at Daily News & Analysis". dna. 5 May 2017. Retrieved 8 May 2017.
- "Bombay HC vacates stay on tree cutting for Metro-3". Asian Age. 6 May 2017. Retrieved 8 May 2017.
- "Stay on tree-cutting for Metro III till Thurs - Times of India". The Times of India. Retrieved 16 May 2017.
- "Supreme Court stays Seepz-Colaba Metro-3 work". Asian Age. 16 May 2017. Retrieved 16 May 2017.
- "Mind sustainability with Metro 3". Free Press Journal. Retrieved 19 February 2017.
- "For funds, Mumbai Metro eyes real estate bonanza in Aarey". The Times of India. Retrieved 10 February 2017.
- "Mumbai: Green tribunal extends stay on Metro construction at Aarey for another month". Hindustan Times. 18 February 2017. Retrieved 18 February 2017.
- "Many legal hurdles in the path of MMRC's Metro 3". The Indian Express. 18 February 2017. Retrieved 18 February 2017.
- "Aarey has been used for non-forest activities since 1949: Maharashtra tells NGT". Hindustan Times. 30 March 2017. Retrieved 30 March 2017.
- "Forest department can't find own report on Aarey forest". http://www.asianage.com/. 11 April 2017. Retrieved 13 April 2017. External link in
- "Mumbai: Aarey eco-sensitive zone matter now posted for hearing in NGT - Times of India". The Times of India. Retrieved 13 April 2017.
- "Clarify stand on approval to Metro III project: Bombay HC to MoEF". mid-day. Retrieved 3 May 2017.
- "Bombay High Court to monitor if cutting of trees for Metro III is in line for building infrastructure or massacre of trees". dna. 25 February 2017. Retrieved 25 February 2017.
- Patel, Shivam. "Look at Kalina for car shed, Metro told". The Hindu. Retrieved 19 February 2017.
- "Mumbai Metro Rail Corporation not to consider Kalina land for depot". The Indian Express. 1 March 2017. Retrieved 2 March 2017.
- "MMRC says Kalina not feasible for Metro car shed, it's back to Aarey". Hindustan Times. 1 March 2017. Retrieved 2 March 2017.
- "Mumbai Metro Rail Corporation redesigns Aarey Metro carshed to save trees". The Indian Express. 2 March 2017. Retrieved 2 March 2017.
- "Aarey car depot may become Parjapur depot | Latest News & Updates at Daily News & Analysis". dna. 6 March 2017. Retrieved 6 March 2017.
- "Sreedharan writes to CM Fadnavis for Metro carshed in Aarey - The Economic Times". The Economic Times. Retrieved 8 March 2017.
- "NGT stay on Metro 3 work vacated: Mumbai Metro Rail Corporation". The Indian Express. 26 March 2017. Retrieved 26 March 2017.
- "Mumbai: Despite NGT order, contractor begins soil testing at Aarey Colony". mid-day. Retrieved 25 March 2017.
- "Alleging violation of NGT orders, environmentalists & tabela owners protest against Mumbai metro | Latest News & Updates at Daily News & Analysis". dna. 25 March 2017. Retrieved 25 March 2017.
- "Mumbai Metro 3: Despite NGT's interim ban, MMRCL tests soil at Aarey Colony". hindustantimes.com. 31 March 2017. Retrieved 1 April 2017.
- "Mumbai: MMRC begins soil survey for Metro 3 construction under police protection". The Indian Express. 31 March 2017. Retrieved 1 April 2017.
- Yerunkar, Chetna (1 October 2017). "Mumbai: As Metro Phase 3 work begins, Flora Fountain is feeling the tremors". Mid Day. Retrieved 27 August 2018.
- "Major contracts involved in our projects". https://www.mmrcl.com. MMRC Official website. Retrieved 27 August 2018. External link in
- "Our projects worldwide". http://en.stec.net. STEC, Shanghai, China - official website. Retrieved 27 August 2018. External link in
- "L&T, partner STEC bag Rs5,273 cr order from Mumbai Metro". Live Mint. 5 July 2016. Retrieved 27 August 2018.
- "Tenders awarded". https://www.mmrcl.com/. MMRCL official website. Retrieved 27 August 2018. External link in
- "Tunneling for Metro-3 to begin by October". hindustantimes.com. 3 March 2017. Retrieved 3 March 2017.
- "Underground tunneling work for Mumbai Metro's Colaba-Bandra-SEEPZ line to begin from Oct". dna. 3 March 2017. Retrieved 4 March 2017.
- "MMRC fabricates first tunnel ring for Metro 3". The Indian Express. 8 March 2017. Retrieved 8 March 2017.
- http://www.thehindubusinessline.com/economy/logistics/mumbai-metro-third-line-to-be-ready-by-2020/article9574308.ece. Retrieved 8 March 2017. Missing or empty
- Our Bureau (2014-03-21). "Tender for Mumbai's Metro phase 3 to be floated in July". Business Line. Retrieved 2014-03-27.
- "MMRC to stick to old method for building most Metro 3 stations". The Indian Express. 29 January 2017. Retrieved 10 February 2017.
- Ranjeet Jadhav (2014-02-17). "MMRDA starts homework to avoid delays in metro line 3". Mid-day.com. Retrieved 2014-03-27.
- "Metro-3 corridor work begins in Mumbai". The Times of India. Retrieved 12 February 2017.
- UK, DVV Media. "Mumbai metro Line 3 breaks ground". Railway Gazette. Retrieved 10 February 2017.
- "Further delay in Metro 3 to push ticket prices up - The Economic Times". The Economic Times. Retrieved 3 March 2017.
- "Metro-3 work begins today, traffic curbs may choke five busy roads - Times of India". The Times of India. Retrieved 18 May 2017.
- "South Mumbai braces for traffic chaos as Metro-3 work begins. Avoid these routes". Hindustan Times. 18 May 2017. Retrieved 18 May 2017.
- "Mumbai underground metro hits roadblock: Fire temple trustees demand Parsi contractor for survey". Firstpost. 4 July 2017. Retrieved 5 July 2017.
- "Wanted: Parsi engineer for Mum Metro | Latest News & Updates at Daily News & Analysis". dna. 2 July 2017. Retrieved 5 July 2017.
- "Shivaji memorial: Mumbai Metro 3 rubble unlikely to be used". The Indian Express. 1 April 2017. Retrieved 1 April 2017.
- "Shivaji Memorial in the Arabian Sea: Statue to tower on green foundation". The Indian Express. 2016-12-24. Retrieved 2017-01-11.
- Chacko, Benita (April 1, 2017). "Shivaji memorial: Mumbai Metro 3 rubble unlikely to be used". The Indian Express. Retrieved 17 September 2018.
- "Mumbai Metro Line III completes 5 km tunnelling". Mumbai Mirror. Retrieved 9 October 2018.
- "Mumbai Metro Line III completes 5 kms tunnelling. See photos". mid-day. 10 July 2018. Retrieved 9 October 2018.
- "Mumbai Metro-3 bores through hurdles to see light at the end of tunnel". dna. 8 October 2018. Retrieved 9 October 2018.
- "MMRC to stick to old method for building most Metro 3 stations". The Indian Express. 29 January 2017. Retrieved 10 February 2017.
- "Mumbai: Metro 3 to go driverless". The Indian Express. 3 March 2017. Retrieved 3 March 2017.
- "Mumbai commute to get seamless: Board a metro, exit at T2 or Mumbai Central terminus". hindustantimes.com. 9 May 2017. Retrieved 11 May 2017.
- "Project Route". MMRCL. Retrieved 2016-01-22.
- "For funds, Mumbai Metro eyes real estate bonanza in Aarey". The Times of India. Retrieved 10 February 2017.
- "Siemens, Tata bidding for Rs 23,136 cr Mumbai Metro | Latest News & Updates at Daily News & Analysis". dna. 7 March 2017. Retrieved 7 March 2017.
- "Mumbai: Metro 3 on track for 2021 inauguration". mid-day. Retrieved 16 May 2017.
- "Mumbai: Buying of Metro 3 coaches stuck due to PM Modi's 'Make in India' scheme". Free Press Journal. Retrieved 9 March 2017.
- "Centre and JICA in a tussle". Asian Age. 9 March 2017. Retrieved 9 March 2017.
- "Made in India trains to run on Mumbai's Metro-3 route". Hindustan Times. 10 May 2017. Retrieved 11 May 2017.
- "Seven firms bid to design and supply Mumbai Metro-3 coaches". hindustantimes.com. 22 June 2017. Retrieved 5 July 2017.
- "Alstom wins €315 million contract to supply cars for Mumbai's metro line 3". The Economic Times. 11 September 2018. Retrieved 9 October 2018.
- "Alstom's Sri City plant to make 31 trains for Mumbai Metro - Times of India". The Times of India. Retrieved 9 October 2018.
- "Driverless Metro train on Colaba-Seepz route - Times of India". The Times of India. Retrieved 3 March 2017.
- "Flyers with heavy luggage will have to rely on taxis, not Metro 3: MMRC | Latest News & Updates at Daily News & Analysis". dna. 4 March 2017. Retrieved 4 March 2017.
- "Cashless travel for Metro-3 passengers". Asian Age. 8 March 2017. Retrieved 8 March 2017.
- Rawal, Swapnil (8 March 2017). "You can use your debit cards to pay for a Metro ride". Hindustan Times. Retrieved 8 March 2017.
- "Bidders line up to design tunnel ventilation and environmental control system - Times of India". The Times of India. Retrieved 24 March 2017.
- "MMRC gets 12 bids for automatic fare collection". Retrieved 24 March 2017.
- "L&T, Godrej, others bid for Mumbai metro job". dna. 22 March 2017. Retrieved 24 March 2017.