Project Labor Agreement
A Project Labor Agreement (PLA), also known as a Community Workforce Agreement, is a pre-hire collective bargaining agreement with one or more labor organizations that establishes the terms and conditions of employment for a specific construction project. Before any workers are hired on the project, construction unions have bargaining rights to determine the wage rates and benefits of all employees working on the particular project and to agree to the provisions of the agreement. The terms of the agreement apply to all contractors and subcontractors who successfully bid on the project, and supersedes any existing collective bargaining agreements. PLAs are used on both public and private projects, and their specific provisions may be tailored by the signatory parties to meet the needs of a particular project. The agreement may include provisions to prevent any strikes, lockouts, or other work stoppages for the length of the project. PLAs typically require that employees hired for the project are referred through union hiring halls, that nonunion workers pay union dues for the length of the project, and that the contractor follow union rules on pensions, work conditions and dispute resolution.
A PLA is authorized under the National Labor Relations Act (NLRA), 29 U.S.C. §§ 151-169. Sections 8(e) and (f) of the NLRA, 29 U.S.C. §§ 158(e) and (f) make special exceptions from other requirements of the NLRA in order to permit employers and unions in the construction industry to enter into PLAs.
The agreements have been in use in the United States since the 1930s, and first became the subject of debate in the 1980s, for their use on publicly funded projects. In these instances, government entities made signing PLAs a condition of working on taxpayer funded projects. This type of PLA, known as a government-mandated PLA, is distinct from a PLA voluntarily entered into by contractors on public or private work—as is permitted by the NLRA—as well as a PLA mandated by a private entity on a privately funded construction project. Executive orders issued since 1992 have affected the use of government-mandated PLAs for federal construction projects and the most recent order, issued by President Barack Obama in February 2009, encourages their use by federal agencies. The use of PLAs is opposed by a number of groups, who argue that the agreements discriminate against non-union contractors and do not improve efficiency or reduce costs of construction projects. Studies of PLAs have mixed results, with some studies concluding that PLAs have a favorable impact, while others find that the agreements can increase costs, and may negatively impact non-union contractors and workers.
- 1 History of PLAs
- 2 Debate over use
- 3 Research and reports
- 4 References
- 5 External links
History of PLAs
The earliest uses of Project Labor Agreements in the U.S. date back to several dam projects in the 1930s, including the Grand Coulee Dam in Washington, the Shasta Dam in California and the Hoover Dam in Nevada. Modern PLAs particularly developed from those used in construction carried out during World War II, a period when skilled labor was in demand, construction unions controlled 87% of the national market and government spending on construction had increased significantly over a short period of time. These early PLAs focused on establishing standard rates of pay and preventing work stoppages. PLA projects that followed included Cape Canaveral in the 1960s, Disney World from 1967–71 and the Trans-Alaska Pipeline from 1973-77. During this period and subsequently, the unionized share of the construction industry precipitously declined as construction users sought more open competition. By the 1980s, nonunion contractors claimed in excess of 80% of the construction work, in a wide variety of trades, with some variation in different parts of the country.
Boston Harbor and executive orders
The Boston Harbor reclamation project that began in the 1980s became the focus of debate over the legality of PLAs. When the Massachusetts Water Resources Authority elected to use a PLA for the project that mandated union-only labor, the Associated Builders and Contractors of Massachusetts/Rhode Island, Inc. challenged its legality, asserting that the use of a PLA was prohibited by the National Labor Relations Act. In 1990, the First Circuit federal appeals court ruled that the Boston Harbor PLA breached federal labor law because of its union-work requirement.
On October 23, 1992, while the Boston Harbor case was still in court, President George H. W. Bush signed Executive Order 12818 prohibiting federal agencies from exclusively contracting union labor for construction projects. Bush's order prohibited the use of PLAs in federal construction projects. The Clinton administration rescinded this order when President Bill Clinton issued Executive Order 12836 in February 1993, shortly after he took office. This order allowed federal agencies to fund construction projects where contractors required a PLA. One month later, in the Boston Harbor cleanup case, the United States Supreme Court unanimously upheld the use of the agreements on public projects. The Supreme Court ruled that if the government was in the role of a regulator, it was not able to require PLA use under labor law preemption principles, however, it could choose to do so as a market participant without being preempted by the National Labor Relations Act. The Court did not address the separate question of whether government-mandated PLAs are lawful under federal or state competitive bidding laws. The decision led to increased use of PLAs in public-sector construction projects throughout the U.S.
In 1997, Clinton proposed an executive order stating that federal agencies must consider use of PLAs for federally funded projects. Republicans staunchly opposed the move, believing it would restrict federal projects to union contractors only. Clinton abandoned the proposed executive order, but issued a memorandum on June 5, 1997, encouraging federal departments to consider the use of PLAs for “large and significant” projects. The memorandum required that government agencies review each project to decide whether a PLA would allow the agency to increase efficiency and reduce costs.
Prohibition for federal projects
On February 17, 2001, President George W. Bush signed Executive Order 13202, “Preservation of Open Competition and Government Neutrality Towards Government Contractors’ Labor Relations on Federal and Federally Funded Construction Projects”, prohibiting the use of PLAs for construction projects with federal funding. This order stated that construction projects receiving federal funding would not be allowed to impose project labor agreements. Specifically, the order declared that neither the federal government, nor any agency acting with federal assistance, shall require or prohibit construction contractors to sign union agreements as a condition of performing work on federally funded construction projects. The order allowed any PLAs that had previously been agreed to continue, and did not affect projects that did not receive federal funding. Bush's order revoked the previous executive order affecting PLAs, Clinton's order 12836, which revoked the executive order issued by President George H.W. Bush in 1992. President George W. Bush issued an amendment in April 2001, allowing certain projects to be exempted from this order, if a contract had already been awarded under an existing PLA at the time of the order.
In August 2001, U.S. District Court ruled Executive Order 13202 invalid in a case examining the use of a PLA by Maryland for the Woodrow Wilson Bridge replacement project. The court ruled that the order was invalid as it conflicted with the National Labor Relations Act. The judge issued a permanent injunction to block enforcement of the order on November 7, 2001. In July 2002, the U.S. Court of Appeals for the District of Columbia overturned the District Court's decision and ordered the removal of the injunction. Following this decision, the Department of Defense, NASA and the General Services Administration formally recognized the order in the Federal Register and implemented it in their construction bidding processes.
Although the Court of Appeals decision in 2002 upheld the executive order prohibiting federal projects from using PLAs, individual states and counties were permitted to use PLAs for some public works where funding was from state and local revenue. These PLAs received opposition by organizations such as the Associated Builders and Contractors, and the Black Contractors Group. A notable example of pro-PLA legislation was passed in New Jersey, which enacted a law in 2002 allowing use of PLAs for some government funded projects.
PLA use since 2009
|Wikisource has original text related to this article:|
On February 6, 2009, President Barack Obama signed executive order 13502, which urges federal agencies to consider mandating the use of PLAs on federal construction projects costing $25 million or more on a case-by-case basis. This act served to revoke the Bush executive orders 13202 and 13208 from eight years earlier that prohibited government-mandated PLAs on federal and federally funded construction projects. The Obama order states that federal agencies can require a PLA if such an agreement will achieve federal goals in economy and efficiency. According to the terms of the order, non-union contractors may compete for contracts subject to PLAs, but they must agree to the various terms and conditions contained in each PLA in order to win a federal contract and build a project. A key change from the 2001 order is that by repealing the Bush orders, the Obama order permits recipients of federal funding, such as state, local and private construction owners, to mandate PLAs on public works projects of any size. However, the order does not encourage or mandate recipients of federal assistance to use a government-mandated PLA.
With the February 2009 stimulus bill allocating approximately $140 billion for federal, state and local construction projects, battles over government-mandated PLAs on public works projects from 2009 to 2011 have been widespread at the state and local government level. Government officials and legislators have clashed over using PLA mandates on projects in states including Iowa, Oregon, Ohio, California, and others. Individual communities have voted on whether to prohibit mandatory PLA use for government projects, including ballot initiatives in Chula Vista, Oceanside, and in San Diego County, California in 2010, which resulted in officials being prohibited from mandating or prohibiting the use of PLAs for government projects. In 2011, contractors filed bid protests with the Government Accountability Office against government mandated PLAs for construction projects in New Hampshire, New Jersey, Pennsylvania and Washington, D.C. These protests led to federal PLA mandates being removed from project solicitations in each case.
At the state level, as of May 2014, through legislation or by executive order issued by the state governor, the following states have banned the requirement that PLAs be used for government funded construction projects: Alabama, Arkansas, Arizona, Georgia, Idaho, Iowa, Kansas, Louisiana, Maine, Michigan, Mississippi, Missouri, Montana, North Carolina, North Dakota, Oklahoma, South Carolina, South Dakota, Tennessee, Utah, and Virginia. States with executive orders, or that have enacted legislation authorizing or encouraging the use of PLAs on public projects include California,  Connecticut,  Hawaii,  Illinois, Maryland,  New Jersey, New York and Washington State.
Debate over use
There has been much debate over the government-mandated PLAs, particularly for publicly funded projects. The use of project labor agreements is supported by the construction unions, and some political figures, who state that PLAs are needed to ensure that large, complex projects are completed on time and on schedule. According to those who support the use of such agreements, PLAs enable project owners to control costs and ensure that there are no disruptions to the construction schedule, for example from strikes. In particular, proponents of PLAs point to the inclusion of clauses in the agreement that agree to establish labor management problem solving committees that deal with scheduling, quality control, health and safety, and productivity problems during the project. They also state that PLAs ensure that the workforce hired has received training and is of high quality. The use of PLAs in large private construction projects such as the building of the New England Patriots' Gillette Stadium, are given as examples of how PLAs help project owners meet tight deadlines, according to supporters. In addition to the stated benefits to project owners, supporters of PLAs also say that PLA use has a positive impact on local communities, through set goals for local hiring and provision of education.
Groups including the Associated General Contractors of America (AGC), Associated Builders and Contractors (ABC), Construction Industry Roundtable (CIRT), National Federation of Independent Business (NFIB), the National Black Chamber of Commerce, and the U.S. Chamber of Commerce have actively opposed the use of PLAs, particularly for government projects. These groups have challenged the use of such agreements through litigation, lobbying, public relations campaigns. Opponents of PLAs supported the Bush executive order prohibiting government-mandated PLAs, and have argued that between 2001 and 2008, when the executive order was in place, no federal projects suffered significant labor problems, delays or cost overruns attributable to the absence of PLAs. According to those who oppose PLAs, the agreements place restrictions on the hiring and working practices of contractors, and can lead to increased costs for project owners. One of their objections to PLAs is that the agreements require contractors to pay into union benefit plans and obey union work rules. In addition, they oppose the use of PLAs to restrict hiring on projects to construction workers selected by unions through union hiring halls, stating that this does not increase the quality of worker as all those who are licensed in a craft have at least the same level of education and skill, regardless of whether they belong to a union.
Another point of debate is the proportion of construction workers who are unionized. According to opponents, under PLAs contractors must hire their workers through unions, and unionized workers are the majority of those who work on PLA projects, despite non-union workers making up the majority of the construction workforce. Estimates of the percentage of construction workers who are non-union, cited by opponents of PLAs, are around 85%, based on figures from the U.S. Department of Labor Bureau of Labor Statistics, and more recent data puts this figure at 86.9%. This figure is disputed by supporters of PLAs, who state that the figures given by those in opposition to PLAs are misleading and are based on census data that encompasses too broad a concept of a construction worker. According to a study by Cornell University in 2010, cited by Mary Vogel, executive director of the Construction Institute, In Massachusetts 60% of the Construction Trades is unionized.Since its inception in 1998, The Construction Institute, a non-profit organization is dedicated to the needs of the unionized construction sector in Massachusetts.
A number of politicians do not agree with the use of the agreements for publicly funded construction projects, and have introduced bills or executive orders that prohibit using the agreements for government projects or prevent the use of public funds for projects using PLAs. These include Louisiana Senate Bill 76, introduced by Senator Danny Martiny, to prohibit state governments from requiring a PLA for projects with government funding. This bill was passed in June 2011, making Louisiana the 5th state in 2011 to ban government requirements that contractors use PLAs for publicly funded construction projects.
Impact on cost
A main argument has been the impact of PLAs on project cost. Those who oppose PLAs state that the agreements impact competition for project bids, reducing the number of potential bidders as non-union contractors are less likely to bid due to the potential restrictions a PLA would pose. According to opponents of the agreements, the reduced competition leads to higher bids and a higher cost for the project owner. In addition, opponents argue that the cost may also be increased due to contractors having greater expenses under a PLA. For example, according to Max Lyons of the Employee Policy Foundation, the cost of a project under a PLA is increased up to 7%, since contractors are required to pay their employees the union wage, rather than the government-determined prevailing wage. Opponents have also argued that there is evidence to show that PLA mandates add costs by forcing non-union contractors to pay into union benefit plans and their existing benefit plans. Supporters of PLA use argue that the end cost of projects is not increased if a PLA is in place, compared to projects without such an agreement, since the agreements prevent cost overruns. In response, opponents of the agreements cite examples of projects a PLA was in place and costs overran including Boston's Big Dig project, Safeco Field in Seattle, and the San Francisco International Airport. Three studies carried out on PLA use in school construction by the Beacon Hill Institute in 2003, 2004 and 2006, found that costs were increased by up to 20% in projects in Massachusetts, Connecticut and New York where PLAs were used. A 2009 study of PLAs use, carried out by Rider Levett Bucknall to determine whether PLAs should be used in the U.S. Department of Veterans Affairs' construction projects, found that costs would increase if PLAs are used for construction projects in locations where union membership is low. According to their analysis, in areas including Denver, Colorado, New Orleans, Louisiana, and Orlando, Florida, where unions do not have a great presence, use of PLAs for projects would lead to cost increases from 5% to 9%. In two cities, San Francisco and New York City, where unions have a great presence, the study predicted mixed results regarding potential cost savings ranging from small project cost increases to small cost savings.
Impact on competition
Opponents of PLAs state that the agreements impact competition for project bids, which can lead to higher costs. It is argued by those who oppose PLAs, such as former ABC president Henry Kelly, that PLAs discourage if not prevent non-unionized contractors from competing for construction projects, particularly federal projects. Competitive bidding statutes discourage public sector PLAs from discrimination between non-union and union contractors, as discrimination between bidders would typically represent a violation of such statutes. Non-union contractors have been awarded contracts on public sector PLA projects, for example the Boston Harbor project. In the United States Supreme Court ruling on the use of a PLA for the Boston Harbor project, it was stated that project owners are within their rights to choose a contractor who is willing to enter into a pre-hire agreement, and that contractors have a choice whether or not they wish to enter such an agreement. However, in a subsequent case the Supreme Court observed the following limitation on the Boston Harbor holding, "In finding that the state agency had acted as a market participant, we stressed that the challenged action "was specifically tailored to one particular job.""
PLAs often require all companies to obtain their workers from union hiring halls, though the union controlling this employee referral system may not discriminate on the basis of a worker's union or non-union status. It is often the case, however, that the hired employees must join a union, usually for the duration of the project. PLA opponents argue that the union control of hiring prevents a non-union contractor for using its own employees. The increased cost to contractors and the impact on their workers of joining a union, is said by opponents of PLAs to discourage non-union contractors from bidding on projects with a PLA. For instance, a project in Ohio in 2010, to build dormitories for two schools saw an increased number of bids when a PLA was no longer required, and the bid prices were 22% lower than they had been when a PLA was in place.
According to supporters, PLAs can be used by public project owners like school boards or city councils to set goals for creating local jobs and achieving social welfare goals through the construction projects they apply to. PLAs may include provisions for targeted hiring and apprenticeship ratio provisions. According to proponents, by including requirements for a certain proportion of local workers to enter union apprenticeship programs working on the construction program, PLAs can be used to help local workers gain skills. The term "Community Workforce Agreement" (CWA) may be used to describe PLAs with community-focused provisions. Proponents state that Community Workforce Agreements re-inject the tax dollars paying for these infrastructure projects back to the communities. Those who oppose PLAs have pointed to examples such as the construction of the Yankee Stadium and the Washington Nationals Ballpark, for both of which community focused agreements were in place but the goals of local hiring and resources to be provided to the community were not met. According to a report for the DC Sports & Entertainment Commission, the PLA for the Nationals Ballpark failed to meet its three main goals of local workers performing 50% of journeyman hours, apprenticeships provided to city residents only, and apprentices to carry out 25% of the work hours on the project. According to groups such as ABC, since the PLAs require that workers are hired through the unions and there are much fewer union workers, this can mean that meeting local hiring goals is impossible.
Impact on minority contractors
A number of women and minority contractor groups oppose project labor agreements, arguing that PLAs disproportionately impact small businesses, particularly those owned by women and minorities. These groups argue that PLAs are anti-free-market and discriminatory. In particular, groups including the National Association of Women Business Owners, have voiced their opposition to PLAs, and in 1998, there was a House hearing dedicated to the issue of minority groups' opposition to government-mandated PLAs. The National Black Chamber of Commerce opposes the use of PLAs due to the low numbers of black union members in the construction industry. According to the NBCC, implementing PLAs leads to discrimination against black workers who are generally non-union workers and also prevents contractors from using casual laborers. According to the United States Pan-Asian American Chamber of Commerce, the majority of their membership comprises small businesses that are unfairly impacted by PLAs, particularly due to increased costs and lowered employee benefits.
Research and reports
A number of studies and reports have been published, aiming at identifying the impact of PLAs. In addition to academic research, reports have been produced by government agencies and individuals on behalf of state or federal government. In 1998 the Government Accountability Office produced a report on PLAs that noted an overall lack of data but reported that both “proponents and opponents of the use of PLAs said it would be difficult to compare contractor performance on federal projects with and without PLAs because it is highly unlikely that two such projects could be found that were sufficiently similar in cost, size, scope, and timing.” The GAO report concluded that it would be difficult to draw "any definitive conclusions" on the impact of PLAs on performance. More recent reports include a favorable study of PLAs from the Cornell University School of Industrial and Labor Relations, in 2009, reports produced by the Beacon Hill Institute since 2003, which conclude that PLAs increase costs of projects, and an analysis published by the National University System Institute for Policy Research, which found that PLAs increased the cost of school construction in California.
In addition to studies examining the use of PLAs and their impact, reports are available detailing the history of PLA use and the arguments for and against their use. Reports examining the history of PLA use, include a 2001 California State Library report, compiled for California State Senate, which recounts the history of PLAs in California and uses case studies to examine the features of public and private PLAs. In a 2001 University of Pennsylvania Journal of Law article, the author outlines the arguments on either side of PLAs and evaluates the state of the law since the 1993 Boston Harbor case decision. The article finds that while there are benefits to PLA use, they can present risks and should only be allowed on projects where they will further the goals of competitive bidding statutes, namely timely, efficient, high quality, and inexpensive construction.
Reports supporting PLAs
Studies have found that PLAs offer benefits to project owners and local communities, and do not disadvantage nonunion contractors and employees. A 2009 study by Fred B. Kotler, J.D., Associate Director of the Cornell University School of Industrial and Labor Relations found that there is no evidence that PLAs discriminate against employers and workers, limit the pool of bidders, and raise construction costs. In a 2009 report by Dale Belman, of Michigan State University; Matthew M. Bodah of the University of Rhode Island and Peter Philips of the University of Utah, the authors stated that rather than increase cost, the agreements provide benefits to the community. According to their report, project cost is directly related to the complexity of a project, not the existence of an agreement. They found that PLAs are not suited to all projects, but some projects are good candidates for their use, such as highly complex construction projects. Studies have also considered how PLAs may benefit communities through hiring locals. In a paper focused on whether PLAs for projects developed by the Los Angeles Community College District (LACCD), the Los Angeles Unified School District (LAUSD), and the City of Los Angeles met local hiring goals, the author found that the goal of 30% local hires set by the PLAs was met.
Reports and studies addressing the cost impact of PLAs on construction projects have found that they may not lead to greater costs, such as a 2002 paper by the Harvard University Joint Center for Housing Studies, which states that the increased costs cited by opponents of PLAs is based on bids rather than end costs. According to the paper, a project's end costs would usually be higher than bid costs due to expenses that arise during construction. In addition, a 2004 report by the Director of General Services for Contra Costa County, California reported that bids for five of eight projects subject to a PLA were lower than the architect/engineer cost estimate. In 2004 a report written on the use of PLAs in Iowa states that PLA use increases efficiency and cost effectiveness of construction projects. "Public-sector PLAs on complex projects or projects where timely project completion is important have been shown to provide the performance desired by contractors and project managers, who repeatedly use them." A 2009 paper concluded that there was difficulty in identifying the effect of PLAs on cost in construction of schools, due to the differences between schools built with PLAs and those built without them. The report stated that there was not any statistically significant evidence for an increase in costs for school construction.
Reports on the legal considerations affecting PLAs make the case that PLAs are an effective tool for labor relations. In a report in 1999, on the legality of PLAs, the authors stated that PLAs "serve as a productive and stabilizing force in the construction industry.” This is supported by a UCLA study that challenged findings of the Beacon Hill Institute on PLAs, which found that in the private sector, the usage of PLAs "creates continuity and stability of the work force at the job site".
Reports opposing PLAs
Several studies by the Beacon Hill Institute (BHI) at Suffolk University in Boston, Massachusetts have concluded that PLAs increase construction costs. Studies in 2003, 2004 and 2006 examining the impact of PLAs on school construction in Massachusetts, Connecticut and New York, respectively, found that where PLAs were in use construction costs were increased, even when controlling for the size of project and type of school. The September 2003 study by the institute found that use of PLAs created a cost increase of almost 14% increase compared to a non-PLA project. The following year their study of PLAs in Connecticut found that PLAs increased costs by nearly 18%. A May 2006 study by BHI found that the use of PLAs on school construction projects in New York between 1996 and 2004 increased construction costs by 20%. This study controlled for the size of the project and type of school. A report on PLAs by BHI, published in 2009, examined whether claims made in Obama's executive order that PLAs have a positive economic impact are correct. The report considered the findings of the institute's studies, further case studies of PLA and non-PLA projects and addressed criticisms of their previous studies and concluded that the justifications for PLA use in the executive order were not proven. In particular the report concluded that there was no economic benefit to taxpayers in using PLAs.
An independently-reviewed 2011 study by The National University System Institute for Policy Research analyzed the cost impact of PLAs on school construction in California from 1996 to 2008. The study analyzed 551 school construction projects and is reportedly the largest study of PLAs to have been undertaken to date. It found that the use of PLAs added between 13% and 15% to construction costs, which would represent a cost increase of between $28.90 and $32.49 per square foot when adjusted for inflation. However, this study's conclusions were strongly disputed by Dr. Dale Belman of Michigan State University, a long-time proponent of the use of PLAs and whose prior research it referenced repeatedly, and who claimed the study misrepresented his findings. He wrote the authors: "Although your study has several serious statistical issues, at the end of the day, your results are basically consistent with those presented in my article on PLAs and Massachusetts school construction costs. The take-away from your results can be summarized as follows: When appropriate controls are included for differences in the characteristics of schools built including school type and location, building specifications, materials used etc., there is no statistical evidence that PLA schools are more costly compared to non PLA schools." Despite Dr. Belman's claims, the Association of California School Administrators and the California Association of School Business Officials released a memo on December 20, 2011 indicating that they found the study's results to be "credible."
In 2010, the New Jersey Department of Labor studied the impact of government-mandated PLAs on the cost of school construction in New Jersey during 2008, and also found that school construction projects where a PLA was used had higher costs, per square foot and per student, than those without a PLA.
Earlier studies also found increased costs when PLAs were used, including a study in 2000 of a Nevada Water Authority project PLA, which found that the project cost an additional $200,000 because the true low bidder refused to sign the PLA. The project then went to a union contractor whose bid was $200,000 higher. Also in 2000, a study commissioned by the Jefferson County, New York Board of Legislators examining the potential use of a PLA for the Jefferson County Courthouse Complex concluded that a PLA could result in additional costs of more than $955,000. The total estimated increase of costs for the projects, should a PLA be used, would have represented 7% of the total cost of the project.
In addition to increased costs of projects, studies have found that PLAs can lead to greater costs for nonunion contractors and can lower their employees' take home pay. A study was produced in 2009 by John R. McGowan of Saint Louis University, which found that nonunion workers on government projects with a PLA in place have reduced wages, compared with what they would receive for work on a non-PLA government project. In addition, nonunion employers would have to pay for additional benefits that their employees would be ineligible for and might be liable for pension fund withdrawal liability costs if the terms of the PLA mean they have to contribute to a union pension fund for the duration of the project.
PLAs also may impact competition by discouraging nonunion bids, according to studies including a September 2001 study by Ernst & Young, commissioned by Erie County, New York. This study analyzed the impact of PLAs on public construction projects and concluded that the number of bidders was reduced for projects with a PLA, as "the use of PLAs strongly inhibits participation in public bidding by non-union contractors." The Worcester Municipal Research Bureau produced a report in 2001, based on a number of studies of PLA use. The report stated that PLAs reduced the number of bidders on construction projects, and led to lower savings than would be possible where contractors are able to work under their usual arrangements for employees. In March 1995, an ABC study of the taxpayer costs for Roswell Park Cancer Institute in Buffalo, New York, assessed bids for the same project both before and after a PLA was temporarily imposed in 1995. It revealed that there were 30% fewer bidders to perform the work and that costs increased by more than 26%.
In terms of wider economic impact, a November 2000 Price Waterhouse Coopers study requested by the Los Angeles Unified School District was not able to confirm whether the project stabilization/labor agreement for the district's Proposition BB construction had produced either a positive or negative economic impact. In March 2006, the Public Interest Institute released a study that concludes that the PLA agreed for the construction of the Iowa Events Center project in downtown Des Moines, placed an “unnecessary burden” on local workers, businesses and taxpayers.
- "Executive Order: Use of Project Labor Agreements for Federal Construction Projects". Retrieved 2009-07-24.
- "Johnston-Dodds, Kimberly. Constructing California: A Review of Project Labor Agreements. California State Library, California Research Bureau Reports, CRB 01010.". Retrieved 2009-07-29.
- "Fred Kotler, Cornell University, ILR School. Project Labor Agreements in New York State: In the Public Interest (March 2009)". Retrieved 2009-07-29.
- "David G. Tuerck, PhD and Paul Bachman, MSIE, Beacon Hill Institute, "Project Labor Agreements and Financing Public School Construction in Massachusetts" (December 2006)". Retrieved 2009-07-29.
- "Building & Constr. Trades Council of the Metro. Dist. v. Ass'd Builders & Contractors of Mass./R.I., Inc., 507 U.S. 218, 231 (1993) (The "Boston Harbor" case)accessdate=2009-07-30".
- Rickman, Bill (2000). "Project Labor Agreements" (PDF). National Alliance For Fair Contracting. p. 5. Retrieved June 10, 2011.
- Northrup, Herbert Roof (2000). Government-mandated project labor agreements in construction: a force to obtain union monopoly on government-financed projects. Wharton School of the University of Pennsylvania. p. 29. Retrieved August 11, 2011.
- Project Labor Agreements. John T. Dunlop, Harvard University Joint Center for Housing Studies (2002).
- "Project Labor Agreements" (PDF). United States General Accounting Office. May 1998. pp. 6–7. Retrieved June 10, 2011.
- Heller, Al (March 1, 2005). "PLAs Grow in Prominence and Gain Critics". New York Construction.
- Greenhouse, Linda (March 9, 1993). "Supreme Court Roundup". New York Times.
- Armstrong, Walter G; Wallace, Ralph M. (January 2001). "A Case Study of Construction Management on the Boston Harbor Project". CM eJournal. CMAA. Retrieved June 10, 2011.
- Neuffer, Elizabeth (October 25, 1990). "US Court Voids Labor Pact on Harbor Cleanup". The Boston Globe.
- "Executive Order 12818 - Open Bidding on Federal and Federally Funded Construction Projects". The American Presidency Project. October 23, 1992. Retrieved June 14, 2011.
- "President Obama Signs Executive Order Allowing Agencies to Require Project Labor Agreements (PLA’s) on Large Construction Projects". McKenna Long & Aldridge LLP. February 10, 2009. Retrieved June 14, 2011.
- Sweeney, Neal J. (2009). Construction Law Update. Wolters Kluwer Law & Business. p. 156.
- "Government Shouldn't Go Where It Doesn't Belong". Engineering News-Record. May 5, 1997.
- "Herman Confirmed After Clinton Drops Executive Order". National Journal's CongressDaily. May 1, 1997.
- "Clinton Memorandum on Labor for Federal Construction Projects". U.S. Newswire. June 6, 1997.
- Executive Order No. 13202
- Murray, Frank J. (July 16, 2002). "Court backs Bush over labor unions in bridge project". The Washington Times. p. A03.
- Brazil, Eric (August 28, 2001). "Judge throws out Bush construction labor order". The San Francisco Chronicle. p. D2.
- "Bush changes order, OKs federal money for Onondaga Lake project to resume". The Associated Press. April 7, 2001.
- Strope, Leigh (November 7, 2001). "Federal judge blocks enforcement of Bush ban on project labor agreements". Associated Press.
- "Bush Administration, Construction Unions In Fight Over Project Labor Agreements". The White House Bulletin. December 5, 2002.
- Miller, Jay (September 10, 2007). "Nonunion, minority contractors keep fighting for county work". Crain's Cleveland Business. p. 8.
- "Recent legislative activity on project labor agreements across the country". The Associated Press. August 9, 2002.
- Baker, Mark; O’Connell, Jonathan E. (May 6, 2010). "New Rule Encourages Federal Agencies to Consider Use of Project Labor Agreements". Mondaq.
- "Use of Project Labor Agreements for Federal Construction Projects". Housing & Urban Development Documents and Publications. August 28, 2009.
- "The Stimulus: What You Need to Know". agc.org. Associated General Contractors of America. Retrieved September 21, 2011.
- Thorman, Chris (November 2, 2009). "State by State: Is the Stimulus Bill Creating Construction Jobs?". Software Advice Inc. Retrieved June 15, 2011.
- Smith, Rick (February 12, 2011). "Input on project labor agreements sought". The Gazette.
- Carinci, Justin (September 23, 2009). "Clash over PLAs grows in Portland". Daily Journal of Commerce.
- Higgins, John (March 20, 2011). "School construction up in air". Akron Beacon Journal.
- Oney, Dan (May 24, 2011). "Vote expected on attaching project labor agreement to L.A. County medical center". PublicCEO.com. Retrieved June 15, 2011.
- "State Labor Agreement Under Scrutiny". Wall Street Journal. June 2, 2011. Retrieved June 15, 2011.
- "Project-Labor Agreement Bill Provides First Fireworks Of Lege Session". The Hayride. April 27, 2011. Retrieved June 15, 2011.
- Greenhouse, Steven (October 14, 2010). "Taking a Vote on Union Construction". The New York Times. Retrieved July 20, 2011.
- Kasler, Dale (June 16, 2011). "Union fight already brewing on new Kings arena". The Sacramento Bee. Retrieved July 20, 2011.
- "ABC Wins Another Challenge Against Government-Mandated Project Labor Agreements on Federal Construction Projects". The Truth About PLAs. January 6, 2011. Retrieved July 5, 2011.
- "Project Labor Revolt". The Wall Street Journal. July 19, 2011. Retrieved July 20, 2011.
- "Snyder signs construction contract legislation". Canadian Business. Associated Press. July 19, 2011. Retrieved July 20, 2011.
- Conlin, Andy (July 13, 2011). "Maine Governor Signs Open Competition Bill Into Law". The Truth About PLAs. Retrieved July 20, 2011.
- Conlin, Andy. "North Carolina Becomes the 18th State to Ban PLA Mandates on Taxpayer Funded Projects". TheTruthAboutPLAs.
- Conlin, Andy. "Mississippi Becomes the 21st State to Restrict PLA Mandates". TheTruthAboutPLAs.
- Dayton, Kevin. "California Governor Signs Union-Backed Senate Bill 922, Intended to End Local Project Labor Agreement Bans". TheTruthAboutPLAs.
- Conlin, Andy. "A Summary of PLA Reform in the States". TheTruthAboutPLAs.
- Conlin, Andy. "Updated: ABC Hawaii Chapter Blasts Gov. Neil Abercrombie’s PLA Directive". TheTruthAboutPLAs.
- "Executive Order on Project Labor Agreements". Illinois.gov. March 31, 2010. Retrieved July 20, 2011.
- Brubeck, Ben. "Gov. O’Malley Issues Executive Order Encouraging the Use of Apprenticeship Programs and Local Hiring Plans in Maryland Public Contracting". TheTruthAboutPLAs.
- "Governor McGreevey Signs Executive Order Supporting Project Labor Agreements". Jersey City Online. Retrieved July, 20 2011.
- "Project Labor Agreements". Local 32, Plumbers and Pipefitters, Seattle. Retrieved July 20, 2011.
- Grimm, Eric (June 15, 2001). "Associated Building Contractors joins President Bush in union fight.". Colorado Springs Business Journal.
- Chase, Dan (April 13, 2009). "Building Controversy". BusinessWest.
- Tuerck, David G. (Winter 2010). "Why Project Labor Agreements Are Not In The Public Interest". Cato Journal.
- Ryan, Mike (July 1, 1999). "Foes of project labor pacts overlook the advantages". Capital Times.
- "UCLA Labor Center, "Construction Careers for our Communities." p. 5, 46.". Retrieved 2009-07-31.
- "AGC Testifies in Opposition to President Clinton's Proposed Executive Order on Project Labor Agreements". PR Newswire. April 30, 1997.
- "Associated Builders and Contractors Project Labor Agreement Resources". Retrieved 2009-07-27.
- "House to Vote on Critical Amendment Promoting Project Labor Agreements Today. Oppose LaTourette Amendment Striking Section 415 of H.R. 2055.". The Truth About PLAs. June 13, 2011. Retrieved July 5, 2011.
- Tuerck, David G. (June 3, 2011). "Hearing on H.R. 735 and Project Labor Agreements: Restoring Competition and Neutrality to Government Construction Projects". Beacon Hill. Retrieved August 10, 2011.
- Petitioner’s Opening Brief, Associated Builders and Contractors v. Metropolitan Water District, Supreme Court Case No. S067485, filed March 19, 1998, p. 18.
- "Wall Street Journal, Union Pensions in the Red: Labor chiefs are doing better than the workers (July 26, 2009)". The Wall Street Journal. 2009-07-26. Retrieved 2009-07-27.
- Larson, Todd (November 4, 2002). "Building Barriers". Boston Business Journal. Retrieved June 7, 2011.
- "Crony Contracts". Wall Street Journal. April 14, 2010. Retrieved June 30, 2011.
- "U.S. Department of Labor Bureau of Labor Statistics Union affiliation of employed wage and salary workers by occupation and industry for 2008". Retrieved 2009-07-28.
- "Union members summary". bls.gov. U.S. Department of Labor Bureau of Labor Statistics Union. January 21, 2011. Retrieved September 21, 2011.
- Erlich, Mark (July 3, 2010). "The truth about PLAs". The Boston Globe. Retrieved June 30, 2011.
- Vogel, Mary (July 6, 2010). "Letter to the Editor featured in boston.com by Mary Vogel, Executive Director of TCI, Facts on PLAs". BuiltBest.org. The Construction Institute. Retrieved June 30, 2011.
- Smith, Rick (12 February 2011). "Input on project labor agreements sought". The Gazette.
- Higgins, John (20 March 2011). "School construction up in air". Akron Beacon Journal.
- Sulon, Bill (5 April 2001). "Bill Would Liberalize Bidding for Pennsylvania-Funded Projects". The Patriot News.
- Mooney, Kevin (28 April 2011). "Louisiana Bill Pre-Empts Union-Backed Project Labor Agreements". Big Government. Breitbart. Retrieved 17 June 2011.
- "Governor Jindal Signs Bills into Law". Office of the Governor, State of Louisiana. June 27, 2011. Retrieved June 30, 2011.
- "Louisiana Bans Government-mandated PLAs on State Funded Projects". The Truth About PLAs. Associated Builders and Contractors. June 28, 2011. Retrieved June 30, 2011.
- "Containing costs on the Silver Line". The Washington Post. June 23, 2011. Retrieved June 30, 2011.
- McGowan, John R. (2009). "The Discriminatory Impact of Union Fringe Benefit Requirements on Nonunion Workers Under Government-Mandated Project Labor Agreements" (PDF). The Truth About PLAs. Retrieved June 30, 2011.
- Balgenorth, Robert J. (July 30, 2000). "Project Labor Agreement Op Ed Article". State Building Trades and Construction Trades Council of California. Retrieved June 30, 2011.
- Beacon Hill Study Finds PLAs Increase Cost of School Projects in Massachusetts (September 2003)
- Beacon Hill Study Finds PLAs Increase Cost of School Projects in Connecticut (September 2004)
- Beacon Hill Study Finds PLAs Increase Cost of School Projects in New York (May 2006)
- Rider Levett Bucknall (June 2, 2009). "Project Labor Agreements Impact Study for the Department of Veterans Affairs" (PDF). The Truth About PLAs. Retrieved July 5, 2011.
- Jolie Siegel, PROJECT LABOR AGREEMENTS AND COMPETITIVE BIDDING STATUTES. University of Pennsylvania Journal of Labor and Employment Law. 3 U. Pa. J. Lab. & Emp. L. 295, 329.
- "Dale Belman, PhD, Michigan State University, Matthew Bodah, University of Rhode Island, and Peter Phillips, University of Utah (2007). Project Labor Agreements, 13.". Retrieved 2009-07-28.
- "Chamber of Commerce of the United States of America, et al., Petitioners v. Edmund G. Brown, JR., Attorney General of California, et al.". Cornell University Law School. June 19, 2008. Retrieved August 10, 2011.
- John T. Callahan & Sons, Inc. v. City of Malden, 713 N.E.2d 955, 958 (Mass. 1999) ('The PLA mandates that this referral system be operated in a manner that is nondiscriminatory to non-union workers....')
- Perritt, supra note 4, at 87; see generally Harms Constr. v. N.J. Tpk. Auth., 644 A.2d 76, 84 (N.J. 1994) (stating that under a PLA an employer recognizes a particular union as the bargaining representative and that any hired workers must join relevant union).
- "Editorial: Second time's a charm". The Columbus Dispatch. November 17, 2010. Retrieved June 30, 2011.
- Kasler, Dale (June 16, 2011). "Union fight already brewing on new Kings arena". The Sacramento Bee. Retrieved June 30, 2011.
- Green, Steve (June 2, 2011). "Contractors ask court to rule on union labor for county jail project". Vegas Inc. Retrieved June 30, 2011.
- "Academic". Retrieved 2009-08-02., "Policy". Retrieved 2009-08-02.
- "Political (LiUNA!)". Retrieved 2009-08-02.
- "Cornejo, Jackie. Building Opportunity: Investing in Our Future through a Port Construction Careers Policy. Los Angeles Alliance for a New Economy (2009)". Retrieved 2009-08-02.
- ""Project Labor Agreements in Iowa: An Important Tool for Managing Complex Public Construction Projects", Ralph Scharnau & Michael F. Sheehan, The Iowa Policy Project (2004).". Retrieved 2009-08-02.
- "Project Labor Agreements and Big Labor Fail at Local Job Creation". The Truth About PLAs. Associated Builders and Contractors. August 5, 2010. Retrieved June 30, 2011.
- Gonzalez, Juan (June 19, 2008). "Bronx officials' deal with Yankees on stadium has become a joke". New York Daily News. Retrieved June 30, 2011.
- "The True Cost of The Washington Nationals Ballpark Project Labor Agreement". DC Progress. Retrieved August 10, 2011.
- Chute, Eleanor (June 21, 2005). "Several protest school board's plan to require union contracts". The Pittsburgh Post-Gazette. Retrieved June 30, 2011.
- Sichko, Adam (April 9, 2008). "Lawmakers pass state budget". The Business Review. Retrieved June 30, 2011.
- "Written Testimony Submitted to House Small Business Committee, August 6, 1998". Retrieved 2009-07-31.
- Alford, Harry. "PLA’s – Ignorance is no Longer Bliss". National Black Chamber of Commerce. Retrieved June 30, 2011.
- Carinci, Justin (23 September 2009). "Clash over PLAs grows in Portland". Daily Journal of Commerce.
- "Minority and Women's Business Groups Oppose Discriminatory Union-only PLAs". Associated Builders and Contractors. Retrieved August 12, 2011.
- Project Labor Agreements: The Extent of Their Use and Related Information. U.S. General Accounting Office, GAO/GGD-98-82, May 1998
- Tuerck, David; Glassman, Sarah; Bachman, Paul (2009). "Project Labor Agreements on Federal Construction Projects: A Costly Solution in Search of a Problem". Beacon Hill Institute. Retrieved June 30, 2011.
- Constructing California, A Review of Project Labor Agreements Johnson-Dodds, Kimberly (2002). At the request of California State Senator John Burton.
- "Project Labor Agreements and Competitive Bidding Statutes" Jolie M. Siegel, University of Pennsylvania Journal of Labor and Employment Law, Volume 3, No. 2, Winter 2001, pp. 295-331.
- ”Project Labor Agreements in New York State: In the Public Interest”. Fred B. Kotler, J.D. Associate Director, Cornell University School of Industrial and Labor Relations. March, 2009.
- Belman, Bodah Phillips http://www.onlinecpi.org/downloads/PLA-report.pdf UCLA Labor Center, "Construction Careers for our Communities.” 2008
- "Construction Careers for Our Communities". Construction Academy. UCLA Labor Center. 2008. Retrieved June 30, 2011.
- Contra Costa County PLA report
- Project Labor Agreements in Iowa: An Important Tool for Managing Complex Public Construction Projects. Ralph Scharnau & Michael F. Sheehan, The Iowa Policy Project (2004).
- Project Labor Agreements’ Effect on School Construction Costs in Massachusetts.
- Legal Considerations Affecting the Use of Public Sector Project Labor Agreements: A Proponent’s View. Bradford W. Coupe, Esq., Morgan, Lewis & Bockius, New York.
- "Project Labor Agreements: The State of the Law", December 1999, by Brian A. Powers and Gerald M. Waites.
- Evaluating PLA Performance? Studies find project labor agreements offer many benefits supporters claim. Cockshaw’s Construction Labor News+Opinion 31(11): 1.
- Vasquez, Vince; Glaser, Dale; Bruvold, W. Erik (July 2011). "Measuring the Cost of Project Labor Agreements on School Construction in California" (PDF). NUS Institute.org. The National University System Institute for Policy Research. Retrieved 20 July 2011.
- Alpert, Emily (July 25, 2011). "Study finds higher costs with labor pacts". Voice of San Diego. Retrieved July 22, 2011.
- Allen, Mike (July 25, 2011). "Study weighs impact of labor agreements on school construction". San Diego Business Journal. Retrieved July 25, 2011.
- "Use of Project Labor Agreements in Public Works Building Projects in Fiscal Year 2008". New Jersey Department of Labor And Workforce Development. October 2010. Retrieved August 10, 2011.
- Labor Agreements Research Study: Focus on Southern Nevada Water Authority (November 2000)
- Analysis of the Impacts on the Jefferson County (NY) Courthouse Complex through Project Labor Considerations (September 2000)
- Erie County (NY) Courthouse Construction Projects: Project Labor Agreement Study (September 2001)
- PLAs on Public Construction Projects: The Case For And Against (May 2001)
- Roswell Park Cancer Institute Letters (March 1995)
- Economic Evaluation of Project Stabilization Agreement For Construction Projects Funded Proposition BB (November 2000)
- Iowa Events Center PLA Study
- The Truth About PLAs - anti-PLA website
- Project Labor Agreements at work for University of Massachusetts UMass Boston’s campus
- Associated Builders and Contractors website on PLAs
- Associated General Contractors of America website on government-mandated PLAs
- PLAs Work - pro-PLA website
- President Obama Executive Order 13502