Aberdeen Western Peripheral Route
![](http://upload.wikimedia.org/wikipedia/commons/thumb/5/58/MilltimberAir.jpg/220px-MilltimberAir.jpg)
![](http://upload.wikimedia.org/wikipedia/commons/thumb/2/29/WPR-19638-Lizzie.jpg/220px-WPR-19638-Lizzie.jpg)
The Aberdeen Western Peripheral Route (AWPR),[1][2][3][4] unofficially also the Aberdeen bypass,[5][6] was a major infrastructure development on the outskirts of Aberdeen, in Aberdeenshire, Scotland. Its primary route is designated as part of the A90 road, with the older road of that designation through the city centre renamed the A92, connecting with the AWPR at either end (Stonehaven in the south and Blackdog in the north).
First announced in January 2003,[7] it was approved by ministers in late 2009, with costs estimated at £295m-£395m.[8] Construction began on 19 February 2015. The final section opened, exactly four years later, on 19 February 2019.[9]
Previously, the only dual carriageway route from north to south was through the city itself, along the original 1930s bypass, Anderson Drive, which was unsuitable for heavy goods vehicles as they could not cross the Bridge of Dee at its south end. The city had expanded beyond Anderson Drive, and a bypass for Aberdeen was first proposed in 1952. In 2012, following lengthy legal delays, the project was approved. Construction began in February 2015, supported by the two local authorities and by NESTRANS, the statutory Regional Transport Partnership for Aberdeen and Aberdeenshire. By 2016 the dual carriageway was projected to cost £745 million.[10] The final section opened in February 2019 - later than planned partly due to weather issues, the January 2018 collapse of contractor Carillion, and concrete problems at the River Don crossing. Giving evidence to the Rural Economy and Connectivity Committee in December 2018, a spokesman for Balfour Beaty agreed that the total cost of the bypass could be "in the area of" £1 billion.[11]
The project also included an upgrade to the dual carriageway of the A90 further north between Balmedie and Tipperty.
Congestion relief
The road was designed to have a positive impact on traffic along routes which are congested during rush hour, particularly Aberdeen's Anderson Drive, King Street and Union Street. Other intentions of this project would be a slight reduction in traffic congestion on the bridges into central Aberdeen, which is sandwiched between the River Dee and the River Don, by reducing heavy goods vehicles that do not need to enter the city. There will also be a reduction in the volume of traffic heading towards Aberdeen Airport, the adjacent industrial estates at Dyce and the new Aberdeen International Business Park. Aberdeen City Council constructed a new six-lane Airport Link Road (ALR) to connect Aberdeen Airport and the business park with the A96 and AWPR, which opened late 2016.
Inquiry
It was argued that the road was important to keep the economy active.[12]
A public local inquiry (PLI) was held in 2008-2009. The PLI recommended adoption of the route[13] and Scottish Ministers approved the route, and it was passed by the Scottish Parliament on 3 March 2010. An appeal was made to the Court of Session based on points including the limited remit of the PLI. The appeal was dismissed[14] and a further appeal was made to the appellate division the "Inner House" of the Court of Session.[15] A yet further appeal was made to the UK Supreme Court. This appeal also failed to overturn the decision to proceed with the route.[16]
Construction
Contract award
On 19 October 2012 a notice was published advising the market that expressions of interest for contractors to construct the route would be made in early 2013 with a view to start construction in late 2014.[17] The initial shortlist of four preferred bidders was reduced to three with the withdrawal of the Scotia Roads Group consortia in September 2013.[18] This left Granite City Roads (Macquarie Capital Group Limited: Vialia; Iridium; Keir Project Investment Limited), North East Roads Partnership (Cintra Infraestructuras, S.A.; John Laing Investments Limited) and Connect Roads (Balfour Beatty Investments Limited; Carillion Private Finance (Transport) Limited; Galliford Try Investments Limited) as the remaining bidders.[19] Keith Brown (Scottish Transport Secretary) also advised that the scheme may open in stages where possible in an effort to relieve existing traffic, with the announcement of the preferred bidder for the contract expected in mid-2014.[20]
The official estimate of the cost of the AWPR was initially £295 - £395 million,[21] although reported figures were in the region of £653 million.[20] Transport Scotland quoted the scheme at £745 million in 2012 prices.[22] Contracts for associated preparation works were announced on the Public Contracts Scotland website.[23]
Contract award was announced on 11 June 2014, with Connect Roads, advised by Pinsent Masons,[24][25] named as the preferred bidder.[26][27] Advance works were already under way, with Scottish Transport Secretary Keith Brown making the announcement of the winning bid from the site of works at Findon Junction.[27][28] A series of public exhibitions around Aberdeen and Shire in June 2014 were also announced by Transport Scotland, to inform the public about progress, advance works, the route and environmental aspects.[29] An £8m "pre-start works agreement" was announced between Transport Scotland and Connect Roads,[30] with the bidder starting fencing, environment surveys and ground investigations ahead of the main works contract commencing later in the year. Other site clearing works and environmental works, such as the relocation of protected badgers, also continued.[31]
Final completion of construction was anticipated in the second half of 2017, about 6 months before the original timescale.[32] The Craibstone interchange was expected to be completed in late 2016 along with the Balmedie to Tipperty section a few months later.[32][33][34][35] Main sub-contracts for the construction phase were published on the Public Contracts Scotland website, with most indicated to begin January 2015.[23][36][37] Transport Scotland also added a current activity page to their AWPR/B-T area, which detailed ongoing works on the project.[38]
Stonehaven campaigners raised concerns over the proposed design for the interchange of the existing A90 dual carriageway and the new Fastlink section of the AWPR. A local farmer offered land for free to support an alternative design for the interchange, but Transport Scotland said changes at this point would add delay and jeopardise the now late-2017 completion date due to road orders and other legal instruments having already been made. They also said the alternative design had been considered and discounted by the design team.[39]
Project mobilisation
Financial close on the project with the winning bidder, now known as Aberdeen Roads Limited, was achieved on 15 December 2014.[40][41][42] It was also announced that lifetime costs for the project (Aberdeen Roads Limited will construct and operate/maintain the route for a period of 30 years) were down by £220m, thanks to innovative new features like a more durable long-life road surface.[43][44] It was also announced that the consortium would be bringing forward the scheduled completion dates for the Craibstone and Dyce Junctions by Autumn 2016 and the Balmedie to Tipperty section by spring 2017, following requests from stakeholders.[45] Scottish First Minister Nicola Sturgeon, along with Cabinet Secretary for Infrastructure Keith Brown, Aberdeen City Council Leader Councillor Jenny Laing and Leader of Aberdeenshire Council, Cllr Jim Gifford, attended the site at Balmedie on 16 February 2015 to perform the ceremonial ground-breaking and officially kick off the start of the works programme.[46][47][48][49][50]
The main site office was constructed at Stonehaven, with a local firm successfully tendering for and providing the temporary accommodation units.[51][52][53] Clearance works for the Balmedie site office were performed during the official ground breaking ceremony and First Minister visit, with the first overhead line safety systems being erected and Flannery Plant heavy machines preparing for works start.[54] The first major traffic management systems for the works included a new 30 mph limit around the Dyce/Goval/Parkhill area roads,[55] and traffic lights and lane closures on the A93 North Deeside Road at Milltimber Brae during May and June to allow for trial digs and utilities re-routing work.[56][57] Aberdeen Roads Limited published its first Project Update newsletter in Spring 2015, detailing current and future works and traffic management measures.[58]
Project delays and cost overruns
Cost overruns on the project were a contributing factor to the January 2018 collapse of Carillion. Connect Roads joint venture partners Balfour Beatty and Galliford Try became jointly liable for additional cash contribution totalling between £60m and £80m; Balfour Beatty estimated a cost of between £35m and £45m,[59] while Galliford Try sought to raise £150m and cut its dividend to support its balance sheet claiming Carillion's collapse had "increased the group's total cash commitments on the project by in excess of £150m".[60] In August 2018, Balfour Beatty said its liabilities on the Aberdeen project had risen by a further £23m and were forecast to reach £135m;[61] in November 2018, Galliford Try said delays would cost an extra £20m, taking its total project hit to £143m.[62]
The first section, a four-mile (7 km) stretch between Parkhill and Blackdog, opened in June 2018,[63] and the Balmedie to Tipperty section opened in August 2018.[64] Carillion's collapse and weather interruptions delayed overall completion of the project; in March 2018, Balfour Beatty said the project would open in late 2018,[65] a date which then slipped to December 2018, partly due to problems involving concrete cladding panels at the River Don crossing.[66][67] In early December 2018, Scottish MSPs heard the final cost of the Aberdeen bypass would exceed £1bn while a 20-mile section of the route would open during the week starting 10 December.[68] The Craibstone to Stonehaven section opened in mid-December but the final 4.5-mile section between Parkhill and Craibstone, including the Don Crossing, was delayed until after Christmas 2018.[69] With the final section still unopened at the end of January 2019, Scottish transport secretary Michael Matheson demanded an urgent meeting with Balfour Beatty and Galliford Try bosses over the continuing delays.[70] The final section opened on 19 February 2019.[9]
In May 2018, Aberdeenshire Council said it would seek compensation from the Balfour Beatty/Galliford Try joint venture for "significant damage" caused to some local roads by transport of thousands of tonnes of materials to the AWPR site.[71]
Following a campaign, in March 2019 a new shared use path was opened allowing users of the Deeside Way to cross the AWPR safely. Despite a route being included in public consultations in 2014, the bypass had opened without a safe path for people using the Deeside Way to cross it.[72]
See also
- New Aberdeen Stadium, a major construction project for the local football club sited alongside the AWPR at the A944
References
- ^ "Aberdeen Western Peripheral Route / Balmedie to Tipperty". Transport Scotland. 24 March 2015. Archived from the original on 17 January 2016. Retrieved 12 May 2016.
- ^ "Aberdeen Western Peripheral Route". Aberdeencity.gov.uk. 3 May 2016. Archived from the original on 17 May 2016. Retrieved 12 May 2016.
- ^ "Archived copy". Archived from the original on 19 March 2015. Retrieved 21 April 2015.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ "Aberdeen Western Peripheral Route : Balmedie-Tipperty : Key Parties" (PDF). Transportscotland.gov.uk. Retrieved 12 May 2016.[permanent dead link]
- ^ Beattie, Kieran (2 April 2018). "Aberdeen Bypass locals voice flood prevention fears". The Press and Journal. Retrieved 7 April 2018.
- ^ "Aberdeen bypass to open 'in April or May'". BBC News Online. 24 January 2018. Retrieved 7 April 2018.
- ^ "Aberdeen gets road bypass". BBC News. 27 January 2003. Archived from the original on 1 September 2003.
- ^ "Aberdeen bypass given green light". BBC News. 21 December 2009. Retrieved 23 April 2010.
- ^ a b "Final section of Aberdeen bypass opens". BBC News. BBC. 19 February 2019. Retrieved 19 February 2019.
- ^ "News". Transport Scotland. Archived from the original on 4 December 2014. Retrieved 12 May 2016.
- ^ Rural Economy and Connectivity Committee 05 December 2018: Aberdeen Western Peripheral Route, Scottish Parliament reports, 5 December 2018
- ^ "Group calls for roundabout change". BBC News. 14 August 2006. Archived from the original on 23 August 2006. Retrieved 23 April 2010.
- ^ "Aberdeen Western Peripheral Route". Scotland.gov.uk. 4 March 2010. Archived from the original on 5 May 2013. Retrieved 12 May 2016.
- ^ "WILLIAM WALTON+JOHN WEIR FRASER+MRS MAGGIE FRASER AGAINST A DECISION MADE BY THE SCOTTISH MINISTERS DATED 21 DECEMBER 2009 FROM THE DIRECTOR OF TRANSPORT v. , 11 August 2011, Lord Tyre". Scotcourts.gov.uk. Archived from the original on 27 May 2013. Retrieved 12 May 2016.
- ^ "Archived copy". Archived from the original on 3 May 2012. Retrieved 18 November 2012.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ "Judgment : Walton (Appellant) v The Scottish Ministers (Respondent) (Scotland)" (PDF). Supremecourt.uk. Archived from the original (PDF) on 1 July 2016. Retrieved 12 May 2016.
- ^ "Archived copy". Archived from the original on 9 October 2006. Retrieved 18 November 2012.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ Fitzpatrick, Tom (18 September 2013). "Bidders down to three on £745m Scottish road schemes | News | Construction News". constructionnews.co.uk. Retrieved 12 May 2016.
{{cite web}}
: Check|archiveurl=
value (help)CS1 maint: url-status (link) - ^ "Strategy". Transport Scotland. 3 January 2014. Archived from the original on 27 October 2014. Retrieved 12 May 2016.
- ^ a b "BBC News - Aberdeen bypass: Sections could open 'ahead of schedule'". BBC News. Archived from the original on 18 February 2014.
- ^ [1] [dead link]
- ^ "Aberdeen Western Peripheral Route / Balmedie to Tipperty". Transportscotland.gov.uk. Archived from the original on 17 January 2016. Retrieved 12 May 2016.
- ^ a b "Documents by Category". Public Contracts Scotland. Archived from the original on 25 April 2016. Retrieved 12 May 2016.
- ^ "Pinsent Masons advises on £745m Scottish Connect Roads win". Legalbusiness.co.uk. 13 June 2014. Archived from the original on 4 June 2016. Retrieved 12 May 2016.
- ^ "Shepherd and Wedderburn advises funders on Scottish aspects of £745m Aberdeen Western Peripheral Route /Balmedie to Tipperty NPD Project | Shepherd and Wedderburn". Shepwedd.co.uk. 18 December 2014. Archived from the original on 4 March 2016. Retrieved 12 May 2016.
- ^ "BBC News - Aberdeen bypass: Preferred bidder named as Connect Roads". BBC News. Archived from the original on 14 June 2014.
- ^ a b "Contractor unveiled for AWPR scheme". Transport Scotland. 11 June 2014. Archived from the original on 27 October 2014. Retrieved 12 May 2016.
- ^ "Archived copy". Archived from the original on 12 November 2014. Retrieved 12 November 2014.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ "Archived copy". Archived from the original on 23 June 2014. Retrieved 23 June 2014.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ "BBC News - Aberdeen bypass: Preparatory work set to start". BBC News. Archived from the original on 2 September 2014.
- ^ Chris Foote. "Badger setts to be destroyed to make way for Aberdeen AWPR bypass - Aberdeen & North - News". STV News. Archived from the original on 13 August 2014.
- ^ a b "Aberdeen bypass to be finished a year earlier than expected". Pressandjournal.co.uk. Archived from the original on 4 March 2016. Retrieved 12 May 2016.
- ^ "Sections of Aberdeen bypass to open early". The Scotsman. 12 December 2014. Archived from the original on 4 June 2016. Retrieved 12 May 2016.
- ^ "AWPR to be completed months ahead of schedule". Pressandjournal.co.uk. Archived from the original on 3 March 2016. Retrieved 12 May 2016.
- ^ "Aberdeen bypass to be completed earlier than scheduled". Evening Express. 28 November 2014. Archived from the original on 5 December 2014. Retrieved 12 May 2016.
- ^ "Firms urged to bid for £100m of work on Aberdeen bypass". Archived from the original on 12 November 2014. Retrieved 12 November 2014.
- ^ "Aberdeen bypass subcontracts advertised". Theconstructionindex.co.uk. 12 November 2014. Archived from the original on 13 May 2016. Retrieved 12 May 2016.
- ^ "Road". Transport Scotland. Archived from the original on 27 October 2014. Retrieved 12 May 2016.
- ^ "AWPR junction will have to be "rebuilt" in five years". Pressandjournal.co.uk. Archived from the original on 3 March 2016. Retrieved 12 May 2016.
- ^ "Carillion consortium achieves financial close on £550 million Aberdeen Western Peripheral Route/Balmedie to Tipperty project". Carillion plc. Archived from the original on 23 September 2015. Retrieved 12 May 2016.
- ^ "Aberdeen peripheral route attracts infrastructure investors to Scotland from across globe | Allianz Global Investors United Kingdom". Allianzglobalinvestors.co.uk. Archived from the original on 4 June 2016. Retrieved 12 May 2016.
- ^ "The Aberdeen Western Peripheral Bypass | The future of Project Bond Financing in Europe". Norton Rose Fulbright. 30 March 2015. Archived from the original on 13 April 2016. Retrieved 12 May 2016.
- ^ "Archived copy". Archived from the original on 2 April 2015. Retrieved 27 March 2015.
{{cite web}}
: CS1 maint: archived copy as title (link) - ^ "Aberdeen Bypass Lifetime Costs Down by Almost £220 million". Transport Scotland. 12 December 2014. Archived from the original on 2 April 2015. Retrieved 12 May 2016.
- ^ "Aberdeen bypass: Airport junctions to open early". BBC News. Archived from the original on 13 February 2016. Retrieved 12 May 2016.
- ^ "FM kicks off work on Aberdeen Bypass". YouTube. 18 February 2015. Archived from the original on 8 May 2016. Retrieved 12 May 2016.
- ^ "Scottish Government on Twitter: "Big cheer for the sod-cutting of the Aberdeen bypass."". Twitterom. 16 February 2015. Archived from the original on 5 March 2016. Retrieved 12 May 2016.
- ^ "First Minister kicks off work on Aberdeen Bypass". Transport Scotland. 16 February 2015. Archived from the original on 1 July 2015. Retrieved 12 May 2016.
- ^ "ScottishGovernment - News - FM kicks off work on Aberdeen Bypass". News.scotland.gov.uk. Archived from the original on 4 March 2016. Retrieved 12 May 2016.
- ^ "Work on bypass finally gets under way". Ellon Times. 19 February 2015. Retrieved 12 May 2016.
- ^ "Founder keeps Aberdeen firm in family hands". Pressandjournal.co.uk. Archived from the original on 4 March 2016. Retrieved 12 May 2016.
- ^ "Media Release: Aberdeen modular cabin firm assembles bypass head office - allmediascotland…media jobs, media release service and media resources for all". Allmediascotland.com. 4 May 2016. Archived from the original on 3 June 2016. Retrieved 12 May 2016.
- ^ "Greenwell secure head office contract for Aberdeen bypass". Project Plant. Archived from the original on 3 June 2016. Retrieved 12 May 2016.
- ^ "P Flannery Plant Hire | Next Day Plant Hire London | Construction Equipment Hire UK". Flanneryplanthire.com. Archived from the original on 10 May 2016. Retrieved 12 May 2016.
- ^ "30mph speed limit in place for work on Aberdeen bypass". Evening Express. 14 April 2015. Archived from the original on 15 April 2015. Retrieved 12 May 2016.
- ^ "Major Aberdeen road to get two months of traffic lights". Evening Express. 28 April 2015. Archived from the original on 28 April 2015. Retrieved 12 May 2016.
- ^ "Commuters facing disruption for 18 months for bypass work". Pressandjournal.co.uk. Archived from the original on 27 May 2016. Retrieved 12 May 2016.
- ^ "Aberdeen Western Peripheral Route : Project Update" (PDF). Transportscotland.gov.uk. Spring 2015. Archived from the original (PDF) on 14 June 2015. Retrieved 12 May 2016.
- ^ "Balfour takes £40m hit on Carillion collapse". The Construction Index. 15 January 2018. Retrieved 15 January 2018.
- ^ Megaw, Nicholas (14 February 2018). "Carillion collapse prompts Galliford Try to cut dividend and raise capital". Financial Times. Retrieved 14 February 2018.
- ^ Prior, Grant (15 August 2018). "Balfour boosts profits despite another Aberdeen road hit". Construction Enquirer. Retrieved 15 August 2018.
- ^ Morby, Aaron (7 November 2018). "Latest Aberdeen bypass delay costs Galliford Try extra £20m". Construction Enquirer. Retrieved 8 November 2018.
- ^ "First main part of £745m Aberdeen bypass opens". BBC News. BBC. 27 June 2018. Retrieved 27 June 2018.
- ^ "Balmedie to Tipperty section of Aberdeen bypass to fully open". BBC News. BBC. 13 August 2018. Retrieved 9 November 2018.
- ^ Morby, Aaron (23 March 2018). "Delayed Aberdeen Bypass pushed back an extra 6 months". Construction Enquirer. Retrieved 23 March 2018.
- ^ "'No definitive date' for £745m Aberdeen bypass opening". Insider.co.uk. 1 November 2018. Retrieved 2 November 2018.
- ^ Morby, Aaron (2 November 2018). "Don bridge hitches delay Aberdeen bypass opening". Construction Enquirer. Retrieved 2 November 2018.
- ^ Tute, Ryan (5 December 2018). "Aberdeen bypass final cost revealed to be "over £1bn" as bosses face politicians". Infrastructure Intelligence. Retrieved 7 December 2018.
- ^ Aaron, Morby (21 December 2018). "Aberdeen bypass now misses Xmas opening deadline". Construction Enquirer. Retrieved 21 December 2018.
- ^ Prior, Grant (30 January 2019). "Contractors face showdown over Aberdeen bypass delays". Construction Enquirer. Retrieved 1 February 2019.
- ^ Garner-Purkis, Zak (4 May 2018). "Balfour-Galliford JV asked to pay Aberdeen road repair bill". Construction News. Retrieved 4 May 2018.
- ^ MacMichael, Simon. "Campaigners win fight to have gap in Deeside Way caused by Aberdeen's £745m bypass plugged". road.cc.
{{cite web}}
: CS1 maint: url-status (link)